Tenders are invited for remediation works to the changeroom building and grandstand at Richmond Oval. The works include construction of a new changeroom building and remediation of the grandstand. Compliance with the Council's online tool for managing contractors' work health and safety systems is mandatory. The contract is expected to commence in October 2026 and be completed by the end of January 2028. A defects liability period of 12 months applies. Security required is 5% of the contract sum. Payment is based on monthly progress claims, with payment within 30 days of the end of the month of assessment. Dispute resolution involves negotiation, mediation, and arbitration.
The date for completion is no later than the end of January 2028. date for completion no later than end january 2028
The Council must pay the assessed amount, including GST but less any retention sum, within 30 days of the end of the month in which the assessment is issued. the council must pay the assessed amount including payment for gst but less any retention sum within 30 days of the end of the month in which the assessment is issued.
The contractor warrants that it has entered into the agreement with full knowledge of existing conditions and has not relied on any advice or statements by the council regarding these conditions. the contractor warrants to the council that is has entered into this agreement with full knowledge of the existing conditions
Tenderers must be suitably qualified. invites tenders from tenderers for the provision of the richmond oval - new changeroom building & remediation works to grandstand
The document does not explicitly state penalties for non-compliance or delays, but it does mention that the contractor bears any cost incurred due to suspension of works if caused by the contractor's act or omission. if caused whether directly or indirectly by any act or omission of the contractor, the contractor bears any cost incurred by it by reason of a suspension under this clause.
The document implies the contractor should have inspected the site as part of their due diligence. it has inspected and has accepted the site and is aware of any relevant physical conditions on the site
The document does not specify a deadline for challenges or objections. null
Failure to comply with the Council's online tool for managing contractors' work health and safety systems will result in a non-conforming submission, which will not be considered during the evaluation process. failure to comply with this requirement will result in a nonconforming submission, and such submissions will not be considered during the evaluation process.
