Mattress Processing for Resource Recovery - Logan City Council ( Council) is seeking to establish a Contract with a suitably qualified and experienced Contractor for the provision of Mattress Processing for Resource Recovery ( WRR/39/2027). The purpose of the Contract is to maximise resource recovery from end- of- life mattresses and reduce the volume of material disposed of to landfill. At a minimum, the Services include the manual or mechanical deconstruction of mattresses and the separation of ferrous
Provision of mattress processing for resource recovery Mechanical shredding of mattresses, separation of ferrous metal from other materials, recovery of foam, textiles and other mattress components, offsite processing and recycling of mattresses, bulk transport of mattresses from council waste and recycling facilities
AI helper
Logan City Council seeks a contractor for mattress processing for resource recovery. Services include mechanical shredding and separation of ferrous metal, with options for onsite processing at Browns Plains facility or offsite processing. Contract term is 2 years with two 2-year extension options. Working hours are 7:00am to 4:30pm Monday to Friday. Contractor must provide safety management system documentation, comply with WHS and environmental regulations, and submit reports within one week of each service. Invoices must be sent electronically. Tender submissions via VendorPanel portal by 24 November 2026.
Services must be performed during hours of 7:00am and 4:30pm Monday to Friday excluding public holidays, unless agreed otherwise by council. the contractor must perform the service during the hours of 7:00am and 4:30pm monday to friday excluding public holidays
Invoices must be issued electronically to ***@***. *. * following completion of each scheduled service or ad hoc request. the contractor must issue electronic invoices to ***@***. *. * in a format prescribed by council following completion of each scheduled service
Contractor must provide evidence of health and safety management system, relevant insurances and public liability documentation. providing evidence and samples of their health and safety management system e. g. , whseq management plan, completed safe work method statements from previous projects
All enquiries must be submitted via the VendorPanel online forum. all enquiries in relation to this tender must be submitted via the vendorpanel online forum
Invoices not displaying required information will be returned to the contractor to be rectified. invoices not displaying the required information will be returned to the contractor to be rectified
Foamed Bitumen Stabilisation/ Building Construction Materials And Services
2027/338 Karadoc Ave & Sixteenth Street Intersection Upgrades & Reconstruction Works - Mildura Rural City Council is seeking Tender responses from suitably qualified contractors to undertake civil construction works associated with the Karadoc Avenue and Sixteenth Street Intersection Upgrade & Sixteenth Street Reconstruction Between Karadoc Avenue and Koorlong Avenue project. ENQUIRIES: Any tender enquiries should be directed to the online forum in VendorPanel. INSPECTION: A site inspection with Council is
Civil construction works for Karadoc Avenue and Sixteenth Street intersection upgrade and Sixteenth Street reconstruction between Karadoc Avenue and Koorlong Avenue Demolition and site preparation works, construction of kerb and channel, construction of new traffic island with tactile ground surface indicators ( TGSI), construction of new roundabout, road pavement works, installation of traffic devices and signage, localised earthworks, adjustment of existing infrastructure, landscaping and reinstatement works, post- project site cleanup
AI helper
Mildura Rural City Council seeks tenders for civil construction works including intersection upgrade and road reconstruction in Irymple, Victoria. Works include demolition, kerb and channel, roundabout, pavement, signage, and line marking. Contract term: Project 1 completion by 31 May 2027, Project 2 by 30 September 2027. Tenders must be submitted electronically via VendorPanel by 15 October 2026. Site inspection available on request, recommended but not mandatory. Evaluation criteria include price, local purchasing, social outcomes, historical performance, and capacity. Successful contractor must meet council's prequalified contractor requirements.
The practical completion date has been set for 31 May 2027 for project 1 and 30 September 2027 for project 2. These dates cannot be negotiated.
Evaluation criteria include price 45, local purchasing, social and sustainable outcomes, ease of doing business and references, historical performance, and capacity.
It is a requirement that the successful respondent, their employees and any subcontractors will meet councils prequalified contractor requirements prior to any works being completed on council property.
A site inspection with council is available on request via the forum. Inspections are highly recommended, however not mandatory.
Hard copy, facsimile, email, verbal or late tenders will not be accepted. All responses must be made by online submission.
Foamed Bitumen Stabilisation/ Building Construction Materials
2027/338 Karadoc Ave & Sixteenth Street Intersection Upgrades & Reconstruction Works - Mildura Rural City Council is seeking Tender responses from suitably qualified contractors to undertake civil construction works associated with the Karadoc Avenue and Sixteenth Street Intersection Upgrade & Sixteenth Street Reconstruction Between Karadoc Avenue and Koorlong Avenue project. ENQUIRIES: Any tender enquiries should be directed to the online forum in VendorPanel. INSPECTION: A site inspection with Council is
Karadoc Avenue and Sixteenth Street intersection upgrade and Sixteenth Street reconstruction works Demolition and site preparation works, construction of kerb and channel, construction of new traffic island with tactile ground surface indicators ( TGSI), construction of new roundabout, road pavement works, installation of traffic devices and signage, localised earthworks, adjustment of existing infrastructure, landscaping and reinstatement works, post- project site cleanup
AI helper
Mildura Rural City Council seeks tenders for civil construction works for the Karadoc Avenue and Sixteenth Street intersection upgrade and Sixteenth Street reconstruction between Karadoc Avenue and Koorlong Avenue, Irymple, Victoria. Works include demolition, kerb and channel, roundabout, road pavement, foamed bitumen stabilisation, asphalt, signage, line marking, and landscaping. Site inspection available on request via VendorPanel forum, recommended but not mandatory. Tenders must be submitted electronically via VendorPanel by 15 October 2026. Evaluation criteria include local purchasing, social and sustainable outcomes, price, ease of doing business, historical performance, and capacity. Practical completion: 31 May 2027 for Project 1 and 30 September 2027 for Project 2. Successful respondent must meet council's prequalified contractor requirements.
The practical completion date has been set for 31 May 2027 for project 1 and 30 September 2027 for project 2. These dates cannot be negotiated.
Evaluation criteria include local purchasing, social and sustainable outcomes, price, ease of doing business and references, historical performance, and capacity.
It is a requirement that the successful respondent, their employees and any subcontractors will meet councils prequalified contractor requirements prior to any works being completed on council property.
A site inspection with council is available on request via the forum. Inspections are highly recommended, however not mandatory.
Hard copy, facsimile, email, verbal or late tenders will not be accepted. Submissions must be fully received by the closing time as late submissions will not be accepted.
Foamed Bitumen Stabilisation/ Building Products Materials
2027/338 Karadoc Ave & Sixteenth Street Intersection Upgrades & Reconstruction Works - Mildura Rural City Council is seeking Tender responses from suitably qualified contractors to undertake civil construction works associated with the Karadoc Avenue and Sixteenth Street Intersection Upgrade & Sixteenth Street Reconstruction Between Karadoc Avenue and Koorlong Avenue project. ENQUIRIES: Any tender enquiries should be directed to the online forum in VendorPanel. INSPECTION: A site inspection with Council is
Karadoc Avenue and Sixteenth Street intersection upgrade and Sixteenth Street reconstruction works Demolition and site preparation works, construction of kerb and channel, construction of new traffic island with tactile ground surface indicators, construction of new roundabout, road pavement works, installation of traffic devices and signage, localised earthworks, adjustment of existing infrastructure, landscaping and reinstatement works, post- project site cleanup
AI helper
Mildura Rural City Council seeks tenders for civil construction works for the Karadoc Avenue and Sixteenth Street intersection upgrade and Sixteenth Street reconstruction between Karadoc Avenue and Koorlong Avenue, Irymple, Victoria. Works include demolition, kerb and channel, roundabout, road pavement, traffic devices, signage, and landscaping. Contract term: Part 1 completion by 31 May 2027, Part 2 by 30 September 2027. Tenders must be submitted electronically via VendorPanel by 15 October 2026. Site inspection available on request, not mandatory. Evaluation criteria include price, local purchasing, social and sustainable outcomes, ease of doing business, historical performance, and capacity. Successful contractor must meet council's prequalified contractor requirements.
The practical completion date has been set for 31 May 2027 for project 1 and 30 September 2027 for project 2. These dates cannot be negotiated.
Evaluation criteria include price, local purchasing, social and sustainable outcomes, ease of doing business, historical performance, and capacity. Price is weighted at 45%.
It is a requirement that the successful respondent, their employees and any subcontractors will meet councils prequalified contractor requirements prior to any works being completed on council property.
A site inspection with council is available on request via the forum. Inspections are highly recommended, however not mandatory.
All responses must be made by online submission. Any response made by any other means open email, facsimile, post or in person will not be considered. Late submissions will not be accepted.
Resin And Rosin And Rubber And Foam And Film And Elastomeric Materials
**** - Rubber Softfall Renewal- The City of Playford invites suitably qualified and experienced contractors to submit tenders for the removal and disposal of existing rubber softfall and the supply and installation of new EPDM rubber softfall at six Council playground and recreation sites. The works include: o Removal and lawful disposal of existing rubber softfall. o Substrate preparation and minor repairs as required. o Supply and installation of new EPDM rubber softfall. o Impact attenuation testing an
Rubber softfall renewal Removal and lawful disposal of existing rubber softfall; Substrate preparation and minor repairs; Supply and installation of new EPDM rubber softfall; Impact attenuation testing and certification; Site- specific works; Project management, handover documentation and warranties.
AI helper
Contractors must submit tenders for removing existing rubber softfall and installing new EPDM rubber softfall at six council sites. Works must comply with AS **** and AS **** must inspect all sites and submit separate pricing for each site. The tender closes at 2:00 pm on September 30, 2026.
Tenderers must inspect all sites and submit pricing for each site separately in accordance with the request for tender documentation.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
