CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
AI helper
Muswellbrook Shire Council seeks submissions from qualified respondents for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** hours 7am-5pm Monday to Friday. Liquidated damages $100 per day. Defects liability period 12 months. Public liability insurance $20 million. Payment claims by 28th day of each month. Security: bank guarantees each 2. 5% of contract sum, retention 10% of each payment until 5% retained. Tender closes 19 November 2026.
The contract states time for payment claims 28th day of each month and the principal must pay the contractor the scheduled amount if any by the date that is 15 business days after the principals representatives receipt of the relevant payment claim.
The contractor warrants all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code.
The council is seeking submissions from appropriately qualified and experienced respondents for the design and construction of the refurbishment works.
liquidated damages rate 100 per day and cap on delay damages nil are specified in the contract particulars.
CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
AI helper
Muswellbrook Shire Council seeks submissions for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** 19 November 2026. Liquidated damages $100 per day. Defects liability period 12 months. Working hours 7am-5pm Monday to Friday. Payment claims by 28th day of each month. Public liability insurance $20 million. Indigenous participation target applies. Local content requirements apply.
Payment claims are made progressively, with the principal paying the scheduled amount within 15 business days after receipt of the claim. As stated: the principal must pay the contractor the scheduled amount if any by the date that is 15 business days after the principals representatives receipt of the relevant payment claim.
The contractor warrants that all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code.
The council is seeking submissions from appropriately qualified and experienced respondents for the design and construction of the refurbishment works.
Liquidated damages are payable at $100 per day for delay beyond the date for completion, as stated in item 17 of the contract particulars.
CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
AI helper
Muswellbrook Shire Council seeks submissions from qualified respondents for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** closes 19 November 2026. Working hours 7am-5pm Monday to Friday. Liquidated damages $100 per day. Defects liability period 12 months. Public liability insurance $20 million. Bank guarantees 2. 5% of contract sum. Retention 10% of each payment up to 5% of contract sum. Indigenous participation target applies.
Payment claims submitted by the 28th day of each month. The principal must pay the scheduled amount within 15 business days after receipt of the payment claim. time for payment claims 28th day of each month
Defects liability period is 12 months commencing on the date of completion. defects liability period 12 months commencing on the date of completion
Liquidated damages rate is $100 per day for delay. liquidated damages rate 100 per day
Campbells Corner Redevelopment - Design and Construct - Muswellbrook Shire Council seeks to engage a suitably qualified and experienced contractor for the design finalisation and construction of the Campbell' s Corner Redevelopment Project in Muswellbrook. The project primarily involves the refurbishment of the vacant retail space within the Campbells Corner building, formerly occupied by the IGA Supermarket, to provide purpose- built Council Chambers and a Boardroom, with the remaining area repurposed as a
Design finalisation and construction of the Campbells Corner redevelopment project, including refurbishment of vacant retail space into council chambers, boardroom, and fresh produce supermarket, with new entry from Bridge Street and modifications to existing café tenancy. Refurbishment of vacant retail space into purpose- built council chambers and boardroom; repurposing remaining area as fresh produce supermarket; construction of new entryway from Bridge Street; upgrades to existing supermarket and café tenancies; roof renovation; associated electrical, fire, hydraulic, mechanical works; demolition services.
AI helper
Muswellbrook Shire Council seeks a suitably qualified contractor for design finalisation and construction of Campbells Corner redevelopment. Mandatory pre-tender meeting and site inspection on 11 September 2026. Tenders due 7 October 2026 via etendering portal. Tender validity 90 days. Evaluation weighted 40% price, 60% non-price criteria including experience, methodology, personnel, local content, timeframe, modern slavery mitigation, subcontractor management, sustainability. Financial assessment required: net tangible assets exceed 5% of contract price, current ratio exceeds 1, working capital exceeds 10% of initial contract price. Two-envelope submission required.
The evaluation uses a weighted scoring process with the ratio of price to nonprice criteria will be 40: 60. Non-price criteria include experience, methodology, personnel, local content, timeframe, modern slavery mitigation, subcontractor management, and sustainability.
Tenderers must demonstrate capacity in work health and safety, environmental management, and financial standing. Financial indicators require net tangible assets exceed 5 of the contract price, current ratio exceeds 1, and working capital exceeds 10 of the initial contract price.
The pre-tender meeting and site inspection is mandatory, scheduled for **** at 11: 00 am commencing at the council administration building. Attendance is limited to a maximum of 3 people per tenderer.
Tenders may be excluded if non-compliant, late, or if collusion is detected. The council may pass over a tender from a tenderer who does not have quality management system certification or fails financial thresholds. Non-compliant tenders may be classified as nonconforming and excluded from consideration.
Campbells Corner Redevelopment - Design and Construct - Muswellbrook Shire Council seeks to engage a suitably qualified and experienced contractor for the design finalisation and construction of the Campbell' s Corner Redevelopment Project in Muswellbrook. The project primarily involves the refurbishment of the vacant retail space within the Campbells Corner building, formerly occupied by the IGA Supermarket, to provide purpose- built Council Chambers and a Boardroom, with the remaining area repurposed as a
Design finalisation and construction of the Campbells Corner redevelopment project, including refurbishment of vacant retail space into council chambers and boardroom, new entry from Bridge Street, and modifications to existing tenancies. Refurbishment of vacant retail space into purpose- built council chambers and boardroom; repurposing remaining area as fresh produce supermarket; construction of new entry from Bridge Street; modifications to existing vacant café tenancy; roof renovation; associated electrical, fire, hydraulic, mechanical works; demolition works.
AI helper
Design and construct contract for Campbells Corner redevelopment in Muswellbrook, NSW. Mandatory pre-tender meeting and site inspection on 11/09/2026. Tenders close 01/10/2026 at 2:00pm. Tender validity 90 days. Evaluation weighted 40% price, 60% non-price criteria including experience, methodology, personnel, local content, timeframe, modern slavery mitigation, subcontractor management, and sustainability. Financial assessment requires net tangible assets exceeding 5% of contract price, current ratio exceeding 1, and working capital exceeding 10% of initial contract price. Tenders submitted via etendering portal in two envelopes: non-price and price information.
The evaluation uses a weighted scoring process with the ratio of price to nonprice criteria will be 40: 60.
Tenderers must demonstrate capacity in work health and safety, environmental management, and financial standing. Financial indicators include net tangible assets exceed 5 of the contract price and current ratio exceeds 1.
The pre-tender meeting and site inspection is mandatory, scheduled for 11/09/2026 at 11:00 am, commencing at muswellbrook shire council administration building, **** bridge street, muswellbrook, nsw, ****.
Tenders may be excluded if non-compliant, late, or if tenderers engage in collusive practices. The council may reject any tender if the relevant tenderer is, or was at any time in the preceding 12 months, involved in any activity that is contrary to the principles of esd.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 30.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".