ITT242 Civil Construction - Caloundra Transport Corridor Upgrade - Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade ( CTCU). The CTCU is made up of two sections - Section 1 and Section 2 with works under the Contract to incorporate, but not be limited to: Separable Portion 1 - Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way - Section 1 and 2: Section 1 ( Works Package A) Duplicating existing traffic lanes to provide two lanes in e
Civil construction Caloundra Transport Corridor Upgrade Separable Portion 1: Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way. Section 1 and 2: Section 1 Works Package A: Duplicating existing traffic lanes to provide two lanes in each direction on Oval Avenue and Third Avenue connecting Oval Avenue with Omrah Avenue via existing Bowman Road. Building a two- way cycle track and pedestrian pathways to be referenced under the contract as Works Package D. Upgrading the following intersections to traffic signals to improve safety and traffic operations: Bowman Road, Gosling Street, First Avenue, Oval Avenue, Third Avenue. Oval Avenue changes to traffic movements at the following locations: First Avenue, Second Avenue and Third Avenue intersections with Oval Avenue. Nicholls Street and Gosling Street intersection. Suller Street, Cowan Street and Omrah Avenue intersections with Bowman Road. Installing new street lighting and landscaping. Section 2 Works Package B: Arthur Street to
AI helper
Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade (CTCU). The project involves two sections and includes duplicating traffic lanes, building cycle tracks and pedestrian pathways, upgrading intersections to traffic signals, installing street lighting and landscaping, and drainage works including box culverts. Respondents are required to price all separable portions. The contractor must have DTM R prequalification to level R3, A3, and F50. A contract is anticipated to be awarded in May/June 2026 with practical completion by December 2027. An information session will be held onsite on 19 March 2026 at 10 am. Tenders close at 12 noon on 12 May 2026. Evaluation criteria include capability and experience, methodology, social and economic factors, and price.
The bid notice states that practical completion of the works is expected by December 2027, with the section between Nicklin Way and Bowman Road to be functionally complete and open to traffic by December 2027.
The evaluation criteria for this tender will be: Stage 1 Mandatory Criteria (Pass/Fail) - TMR prequalified certifications, workplace health and safety, insurances, licences. Stage 2 Non-price weighted evaluation criteria. Stage 3 - Price, Financial Capacity. The evaluation criteria are: Capability and Experience (15%), Methodology (30%), Social and Economic Factors (15%), Price (40%).
The contractor must have and maintain for the life of the contract, Department of Transport and Main Roads (DTMR) prequalification to prequalification level R3, A3, and F50 to be eligible to provide a tender response and be considered for award of this contract.
An information session will be held onsite on 19 March 2026 at 10 am. Respondents are encouraged to attend the information session to familiarise themselves with the site, project requirements, opportunities and constraints.
Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Infrastructure Development/ Zero Net Energy By 2040
ITT242 Civil Construction - Caloundra Transport CorridorUpgrade - Tenders are invited for the civil construction of the Caloundra Transport Corridor Upgrade ( CTCU). The CTCU is made up of two sections - Section 1 and Section 2 with works under the Contract to incorporate, but not be limited to: Separable Portion 1 - Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way - Section 1 and 2: Section 1 ( Works Package A) Duplicating existing traffic lanes to provide two lanes in e
Civil construction Caloundra Transport Corridor Upgrade Separable Portion 1: Caloundra Transport Corridor between Omrah Avenue and Industrial Avenue Nicklin Way. Section 1 Works Package A: Duplicating existing traffic lanes, building a two- way cycle track and pedestrian pathways ( Works Package D). Upgrading intersections to traffic signals. Changes to traffic movements. Installing new street lighting and landscaping. Section 2 Works Package B: Arthur Street to Industrial Avenue Nicklin Way. Nicklin Way Third Avenue Extension. Connection of Industrial Avenue to Nicklin Way. Upgrading intersection of Arthur Street/Third Avenue to traffic signals. Installation new street lighting and landscaping. Package D: CTCU Section 1 Cycle Track Infrastructure. Separable Portion 2: Arthur Street Drainage Upgrade Works Package C: New box culvert along Arthur Street, new box culverts crossing Arthur Street.
AI helper
This is a public tender for the civil construction of the Caloundra Transport Corridor Upgrade (CTCU). The project involves two sections and includes duplicating traffic lanes, building cycle tracks and pedestrian pathways, upgrading intersections, and installing new street lighting and landscaping. Respondents are required to price all separable portions, as the intention is to award all portions to one principal contractor. A non-conforming tender will result from any departure from this requirement. The contractor must hold DTM R prequalification levels R3, A3, and F50. A contract is anticipated to be awarded in May/June 2026, with practical completion by December 2027. The section between Nicklin Way and Bowman Road must be functionally complete and open to traffic by December 2027. An information session will be held onsite on March 19, 2026, at 10 am. Tenders close at 12 noon on May 12, 2026. All enquiries must be submitted in writing via email to ***@***. *. *, referencing contract number ITT242. Tenders must be submitted electronically through VendorPanel Marketplace.
The bid notice states that practical completion of the works is expected by December 2027, with the section of the corridor between Nicklin Way and Bowman Road to be functionally complete and open to traffic by December 2027.
The evaluation criteria for this tender include mandatory criteria (DTMR prequalification, WHS, insurances, licences), non-price weighted evaluation criteria (capability and experience, methodology, social and economic factors), and price.
The contractor must have and maintain, for the life of the contract, Department of Transport and Main Roads (DTMR) prequalification to prequalification level R3, A3, and F50 to be eligible to provide a tender response and be considered for award of this contract.
An information session will be held onsite on 19 March 2026 at 10 am. Respondents are encouraged to attend the information session to familiarise themselves with the site, project requirements, opportunities and constraints.
The cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Gaseous Fire Suppression Industry Report - Provision of a Gaseous Fire Suppression Industry Report to the Department of Climate Change, Energy, the Environment & am- The Department of Climate Change, Energy, the Environment and Water ( the Department) is seeking to commission a report on the gaseous fire suppression use of extinguishing agents scheduled under the Ozone Protection and Synthetic Greenhouse Gas Management Act ****, as it relates to Australia s regulation of ozone depleting substances ( ODS)
Gaseous fire suppression industry report
AI helper
The Department of Climate Change, Energy, the Environment and Water is seeking submissions for a comprehensive state-of-the-industry report on gaseous fire suppression and non-defence halon use in Australia. The report will provide up-to-date data on imports, installed banks, usage, decommissioning, regulatory trends, and future demand modelling for scheduled extinguishing agents, including HFCs to 2036 and Halon to 2050. The output will inform policy development, support the implementation of the HFC phasedown, and ensure ongoing management of halon stocks. Responses must be lodged electronically via Austender by Friday, 1st May 2026, 2:00 PM AEST. Questions regarding the tender can be submitted until Tuesday, 28 April 2026, 5:00 PM AEST. The contract term is 6 months with a potential 3-month extension option. Key deliverables include a comprehensive report and an interactive, user-friendly stock model. The department will provide relevant data and letters of introduction for stakeholder engagement. Potential suppliers must comply with the Commonwealth Approach to Market Terms and the Commonwealth Contract Terms.
The draft report and model are due by 15 October 2026, and the final report and model are due by 15 December 2026.
The customer must pay the amount of a correctly rendered invoice to the supplier within twenty (20) calendar days after receiving it, or if this day is not a business day, on the next business day.
The customer will evaluate all valid responses received by the ATM closing time that meet the minimum content and format requirements and the conditions for participation to determine which potential supplier has proposed the best value for money outcome for the customer.
Potential suppliers are required to comply with all requirements set out in the Commonwealth Approach to Market Terms and, if successful, agree to enter into a contract which incorporates the Commonwealth Contract Terms.
Questions will be permitted up until 5:00 PM AEST Tuesday, 28 April 2026.
Renewing Renewables Feasibility Study- In January 2026, the Australian Government announced a $ 25 million national photovoltaic ( PV) recycling pilot program to inform the development of a future national product stewardship scheme. In this context, the South Australian Government, through the Department of State Development in collaboration with Green Industries SA, is undertaking a feasibility study to assess the potential for establishing an end of life solar panel recycling hub in South Australia,
Renewing Renewables Feasibility Study- In January 2026, the Australian Government announced a $ 25 million national photovoltaic ( PV) recyclingpilot program to inform the development of a future national product stewardship scheme. In this context, the South Australian Government, through the Department of State Development in collaboration with Green Industries SA, is undertaking a feasibility study to assess the potential for establishing an end of life solar panel recycling hub in South Australia,
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Start your free trial and receive email alerts
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/territories, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits Australia (1035 real users, 14/04/2026).Methodology
They deliver on their promises. The information is simple and straightforward.
G. G
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
We selected the most helpful reviews from real users. Order may change periodically.
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
It encompasses all portals in one place.
G. Ferrea
The platform is very user-friendly.
N. Lobato
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
Sending job opportunities via email is very good. Their information sources are rich in opportunities. The ease of use and advanced search options also make the work easier. The great advantage is the well-organized compilation that facilitates the search for opportunities.
V. De Folga
I am very satisfied; it's a very useful tool.
J. S. Garcia
It is complete and optimal, it improves my time.
R. de L. Cruz
I quickly find the tenders that interest me.
S. Roque
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
BidHits Australia is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the Commonwealth, state/territory and local council levels. Tenders are added to the system as soon as they are published on the source portal.
Plans start at A$ 65.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia. Start by adding a few keywords. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits Australia now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1035 active users, conducted through 14/04/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
