Building Remediation/ External Building Maintenance/ Building Trade/ Painting Supplies Services/ Building Maintenance Services
Tully Civic Centre External Building Remediation, Repainting and Signage Works - Cassowary Coast Regional Council is seeking quotations from suitably qualified contractors for the **** - Tully Civic Centre External Building Remediation, Repainting and Signage Works located at 34- 40 Bryant Street, Tully QLD 4854. The Works generally include external building remediation and repainting works, scaffolding and access requirements, removal and installation of signage, cleaning and preparation of external surf
External building remediation, repainting and signage works External building remediation, repainting, scaffolding, access requirements, signage removal and installation, cleaning and preparation of external surfaces.
AI helper
Cassowary Coast Regional Council seeks quotations for external building remediation, repainting, and signage works at Tully Civic Centre. The works include remediation, repainting, scaffolding, signage removal/installation, and surface preparation. A mandatory site inspection is held on 23/09/2026. Quotations must be submitted via VendorPanel by 01/10/2026 17:00 AEST. Evaluation criteria include price (30%), program (25%), methodology (25%), experience (10%), and local content (10%). The works must be completed by 31/05/2027. If Dulux paint is used, notification to Dulux is required at least 7 days prior to commencement.
The works must be completed by 31 May 2027.
Respondents must provide all required warranties, manuals, product information and handover documentation for practical completion.
Evaluation criteria weighting price 30 program 25 methodology 25 experience 10 local content 10.
Respondents are required to submit a proposed program for the works.
A site inspection is held at **** Bryant Street Tully on Wednesday 23rd September 2026 at 10:00am.
Commercial Painting and Related Services - Commercial Painting & Related Services which includes but is not limited to - wash down services, full repaints, touch- ups, pressure cleans, anti- slip coatings, graffiti removal and ad hoc services. Council is seeking Tenders from suitably qualified Suppliers to provide their services in relation to; a) SP1 - Painting & Pressure Washing b) SP2 - Graffiti Removal c) SP3 - Anti- Slip Coatings - Please see attached Specifications
Commercial painting and related services SP1 - painting & pressure washing, SP2 - graffiti removal, SP3 - anti- slip coatings
AI helper
Council is seeking tenders for commercial painting and related services, including wash down, full repaints, touch-ups, pressure cleans, anti-slip coatings, and graffiti removal. The services are divided into three separable portions (SP1, SP2, SP3). Tenders must be submitted via the tender portal by 2pm AEST on October 8, 2026. Evaluation considers best value for money, including methodology, experience, and price.
Tenders shall be assessed by an evaluation panel. . . to ascertain the best value for money for council. The evaluation panel will take into consideration the effectiveness of each submission in comparison witheach quoted prices to ascertain the best value for money for council.
Tenders must include organisational experience and individual experience along with capacity to service the contract.
Tenders may be rejected if they does not comply in every respect with the requirements of the rft documents including these rft conditions.
Building Maintenance/ Building Trade/ Plumbing Maintenance Supplies Services/ Building Construction Materials Services
****- ****- Lot134 Egrue Village, Erub ( DISMOD- Bathroom) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refer to the following information
Bathroom upgrades Lot 134 Egrue Village, Erub - Bathroom
AI helper
The engagement of services will be awarded to the respondent who best demonstrates the ability to provide best value for money. The contractor must complete the quotation form and response schedules. The lump sum price breakdown schedule must be fully completed. Works must be programmed to ensure minimal disruption to normal tenant requirements. The contractor is responsible for health and safety of all persons and property, including tenants. The contract is subject to referenced documents including QBuild general terms and conditions.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.
If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. please complete 7. 3 lump sum price breakdown schedule if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.
RFT26- 019 College Avenue Reconstruction - The City' s objectives with this Request for Tender are to engage a suitably qualified and experienced Contractor to design, reconstruct and resurface a 1. 62 km section of College Avenue in Busselton. The existing pavement has asphalt surfacing with notable deterioration requiring a combination of reconstruction and resurfacing. This urban road supports high traffic volumes, and all works will be conducted at night to minimise disruption. A concept design, reconst
Road reconstruction and resurfacing Reconstruction and resurfacing of a 1. 62 km section of College Avenue in Busselton, including asphalt overlay, limestone basecourse, concrete infill, and path construction.
AI helper
The City of Busselton seeks a contractor to design, reconstruct, and resurface a 1. 62 km section of College Avenue. All works must be conducted at night to minimize disruption. A concept design, reconstruction methodology, and durable surfacing solution for a minimum 30-year design life are required. The tender opens on 11 September 2026 and closes on 14 October 2026.
Building Materials/ Panel Supply/ Building Products/ Materials Supply
SMRC Concrete Panel - SMRC invites submissions from suitably qualified and experienced concrete suppliers for inclusion in Council' s concrete supply panel ( the Panel). The Panel will comprise a range of suitably qualified and experienced concrete suppliers capable of supporting Council' s day- to- day operational activities across various service areas. Successful Respondents will be appointed to the Panel and may be engaged by Council to provide materials on a ' as required' basis in accordance with an a
Concrete panel supply Concrete materials for council' s day- to- day operational activities across various service areas.
AI helper
SMRC invites qualified concrete suppliers for a concrete supply panel to provide materials on an 'as required' basis. The panel aims to ensure timely, efficient, and value-for-money access to concrete materials for maintaining community assets. Submissions are open from September 13, 2026, to October 19, 2026. Suppliers must adhere to the council's code of conduct and ethical standards.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Excellent information. Just what I was looking for.
L. H. Borrelli
Fast, flexible, and simple.
E. Disruptivas
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They notify me promptly when a contest is published.
L. Salazar
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I am very satisfied; it's a very useful tool.
J. S. Garcia
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I quickly find the tenders that interest me.
S. Roque
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
