Texas STP upgrade Pond works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Maturation Pond 1 Package and includes the construction, testing, commissioning of a Pond and associated infrastructure, as detailed in the Contract Documents.
Construction, testing and commissioning of Maturation Pond 1 package at Texas Wastewater Treatment Plant upgrade Mobilisation and demobilisation, maturation pond 1 construction including earthworks and embankments, geomembrane liner system, inlet and outlet weirs and reinforced concrete structures, drainage pump station, mixer installations, site pipework, electrical conduits and pits, testing and commissioning, closeout documentation
AI helper
Lump sum contract for construction of Maturation Pond 1 at Texas WWTP. Completion required by 17 December 2027. Tender closes 4pm EST 4 November 2026. No mandatory site visit but requests welcome. 10% retention from progress payments, 50% released at practical completion, 50% at end of 12-month defects liability period. 12-month workmanship warranty. Public liability insurance of $20 million required. Tender validity 90 days. Submissions via Vendor Panel.
Completion of all works, including commissioning, is required by 17 December 2027. The document states: completion of all components of the works, including commissioning, is required by 17 december 2027.
Progress claims may be submitted for works fully executed on site or materials delivered to site. The document states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.
The contractor must provide a 12-month warranty on all workmanship from practical completion. The document states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
Contractors must have necessary skills and expertise. The document states: the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works.
Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.
No mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
Direct contact with council employees is prohibited and will result in disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
Minor & Major Civil Works Panel - This tender is for the establishment of a panel of pre- qualified suppliers /contractors for the undertaking Minor & Major Civil Works at various locations within the MidCoast Council Local Government Area as part of Council' s operations. This contract is to compliment Council' s various panel contracts to enable Council to implement its Delivery Program and Operational Plan effectively. Works shall include but not be limited to; bulk earthworks, construction of road pave
Establishment of a panel of pre- qualified suppliers/contractors for minor and major civil works at various locations within the MidCoast Council local government area. Bulk earthworks, construction of road pavement, stormwater drainage, concreting works, sediment and erosion control, landscaping, retaining walls, fencing, signposting, excavation, filling, grading, compaction, road pavement maintenance and rehabilitation, gravel resheeting, shoulder repairs, asphalt or bituminous surface resurfacing, stormwater drainage construction, repair and replacement, pipes, pits, culverts, headwalls, table drains, drainage outlets, kerb and gutter, footpaths, shared paths, access ramps, driveways, vehicle crossings, slabs, minor concrete repairs, installation, maintenance and removal of erosion and sediment controls, site rehabilitation, topsoiling, turfing, seeding, revegetation, construction and repair of minor retaining walls, installation, repair and replacement of fencing, gates and bollards, installation and rep
AI helper
This tender establishes a panel of pre-qualified suppliers/contractors for minor and major civil works within the MidCoast Council LGA. The contract is for 3 years with two 12-month options. Works include bulk earthworks, road pavement construction, stormwater drainage, concreting, erosion control, landscaping, retaining walls, fencing, and signposting. Contract sum is exclusive of GST. Contractor must have public liability insurance with a limit of not less than $20 million. Invoices submitted monthly, payment within 15 business days of approval. Defects liability period is 12 months. Claims must be notified within 28 days of becoming apparent. Disputes to be resolved in person within 7 days.
The contractor must perform the services by the completion date. The contractor shall give the principal 14 days written notice of the date upon which the contractor anticipates that practical completion will be reached. the contractor must: a commence the services on the start date of this agreement and b provide the services by the completion date
The contractor may submit a tax invoice on the 25th day of each month. Payment of approved invoices must be made within 15 business days of receipt. payment of the invoice or that part of the invoice which has been approved must be made within 15 business days of receipt of the invoice
The contractor guarantees the services shall be fit for their intended purpose. guarantees to the principal that the services shall be fit for their intended purpose.
This tender is for the establishment of a panel of pre-qualified suppliers/contractors. this tender is for the establishment of a panel of pre-qualified suppliers /contractors for the undertaking minor & major civil works
If the contractor breaches terms, the principal may employ and pay others to remedy the default at the contractor's cost. the principal may give notice in writing to the contractor describing the default and stating that if it is not remedied within 14 days of sending the notice, the principal may employ and pay others to remedy the default at the contractors cost.
All money claims must be notified within 28 days of the date when the claim reasonably became apparent. the contractor within 28 days of the date when the claim reasonably became apparent notifies the principal of the claim in writing
Failure to comply with the modern slavery clause can lead to termination. if the contractor fails to comply with the obligations in clause 26, then the principal may at any time thereafter. . . terminate the contractors services by giving notice of termination.
Texas STP upgrade Pond works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Maturation Pond 1 Package and includes the construction, testing, commissioning of a Pond and associated infrastructure, as detailed in the Contract Documents.
Construction, testing and commissioning of Maturation Pond 1 package at Texas Wastewater Treatment Plant upgrade Maturation pond 1 construction including earthworks and embankments, geomembrane liner system, inlet and outlet weirs and reinforced concrete structures, drainage system and pump station, mixer installations with council- supplied mixers, site pipework with valves and fittings, electrical conduits and pits, testing and commissioning, mobilisation and demobilisation, closeout documentation
AI helper
Lump sum contract for construction of Maturation Pond 1 at Texas WWTP, Queensland. Tender closes 4pm EST 4 November 2026. Completion required by 17 December 2027. No mandatory site visit but requests welcome via Vendor Panel. Prices inclusive of GST, no rise and fall. 10% retention per progress payment, 50% released at practical completion, 50% at end of 12-month defects liability period. 12-month workmanship warranty. Evaluation criteria include price, past performance, methodology, WHS systems, availability and local content. All submissions via Vendor Panel.
Completion of all components of the works, including commissioning, is required by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027
Progress claims may be submitted for works fully executed on site or materials delivered to site. progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use
The contractor must provide 12 months warranty on all workmanship from practical completion. the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection
Contractors must have necessary skills and expertise and complete the WHS questionnaire. the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works
Failure to maintain progress may result in liquidated damages. failure to maintain progress in accordance with the approved project schedule. . . may result in the application of liquidated damages or other applicable contractual remedies
No mandatory site visit, but requests are welcome via Vendor Panel. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome
Canvassing or direct contact with council employees is prohibited and will result in automatic disqualification. any form of canvassing or direct contact with council employees, councillors, or consultants, is strictly prohibited. . . will result in automatic disqualification
EOI for Callide Electorate Office Refurbishment ( Biloela, QLD) - QPS is seeking interest from qualified building companies to project manage and refurbish the Callide Electorate Office located at 64 Callide Street, Biloela Qld **** refer to the following documents for further details of this Expression of Interest ( EOI). If your company is interested in being involved in the Invitation to Tender ( ITO) phase for this refurbishment of the Callide Electorate Office, please submit a response to this
Refurbishment of the Callide electorate office Office fitout including partitions, ceilings, glazing, doors, floor coverings, paint, window coverings, workstations, loose furniture, joinery, reception counter, kitchenette, air conditioning, electrical, lighting, power outlets, hot water system, telecommunications, structured cabling, audio visual, security systems, MATV, fire services, signage, and relocation services
AI helper
QPS seeks interest from qualified building companies to project manage and refurbish the Callide electorate office at 64 Callide Street, Biloela QLD **** responses due by 16 November 2026. Successful respondents will be invited to the tender (ITO) phase. The fitout must comply with relevant legislation, Australian standards, and the National Construction Code. Scope includes partitions, ceilings, glazing, doors, finishes, workstations, joinery, air conditioning, electrical, telecommunications, security, fire services, signage, and relocation of office contents. A provisional allowance of $6,000 for advertising signage is noted.
A minimum warranty period of 5 years is required on all parts and components for workstations and loose furniture, as stated: A minimum warranty period of 5 years is required on all parts and components.
Contractors must hold relevant licenses and registrations, including: All contractors must provide and hold a class 2 license for queensland and registered contractors with an open registration for ICT cabling work.
Texas STP upgrade Pond works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Maturation Pond 1 Package and includes the construction, testing, commissioning of a Pond and associated infrastructure, as detailed in the Contract Documents.
Construction, testing and commissioning of maturation pond 1 package at Texas Wastewater Treatment Plant upgrade Maturation pond 1 construction including earthworks and embankments, geomembrane liner system, inlet and outlet weirs and reinforced concrete structures, drainage pump station, mixer installations, site pipework, electrical conduits and pits, testing and commissioning, closeout documentation
AI helper
Lump sum contract for construction, testing and commissioning of maturation pond 1 at Texas WWTP. Tender closes 4pm EST 4 November 2026. Completion required by 17 December 2027. No mandatory site visit but requests welcome via Vendor Panel. Prices inclusive of GST. 10% retention from progress payments. 12 months warranty on workmanship. Public liability insurance $20 million. Submission via Vendor Panel. Evaluation based on price, past performance, methodology, WHS systems, availability and local content.
Completion of all works including commissioning is required by 17 December 2027. The document states: completion of all components of the works, including commissioning, is required by 17 december 2027.
Progress claims may be submitted for works fully executed on site or materials delivered to site. The document states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.
The contractor provides 12 months warranty on all workmanship from practical completion. The document states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
Contractors must have necessary skills and expertise. The document states: the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works.
Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.
No mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
Direct contact with council employees or councillors results in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Plans start at A$ 30.00/month, with options for different needs and subscription terms. Plans are prepaid: check the total amount and duration before confirming. Start with the free trial and assess the results before subscribing, with no automatic charges.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
