RFT2027/3 Design & Construct Gundagai WTP CCP Instrumentation & Integration Upgrade - Cootamundra- Gundagai Regional Council is seeking submissions from suitably qualified and experienced contractors for the design and construction of upgrades to the Gundagai Water Treatment Plant, including Critical Control Point ( CCP) instrumentation and integration works, with an optional chemical dosing system upgrade. - The Tenderer must familiarise themselves with the Works and the Site before submission. Tenderers
Design and construction of Gundagai Water Treatment Plant critical control point instrumentation and integration upgrade, with optional chemical dosing system upgrade Critical control point ( CCP) instrumentation and integration upgrade, optional chemical dosing system upgrade, optional actuator valve upgrade
AI helper
Design and construct upgrade of Gundagai WTP CCP instrumentation and integration, with optional chemical dosing and actuator valve upgrades. Mandatory site inspection on 12 October 2026. Tender closes 29 October 2026. Completion within 20 calendar weeks, by 30 April 2027. Liquidated damages **** per day. Retention 4% via bank guarantee. Professional indemnity insurance $5 million required.
The time for completion is 20 calendar weeks after acceptance of tender, must be completed before 30 April 2027. The time for completion is: 20 calendar weeks after the date of acceptance of the tender. Must be completed before 30 april 2027
Payment claims are to be made monthly, on and after the 25th day of each calendar month. Payment claims are to be made: monthly, on and after 25th day of each calendar month.
Liquidated damages are **** per day for late completion. The rate per day for liquidated damages is: ****
A mandatory site inspection will be held on Monday 12 October 2026 at 11:00 am. A mandatory site inspection will be held as per the details provided below
RFT2027/6 Asphalt Works at Five Locations - Cootamundra- Gundagai Regional Council is seeking tenders from suitably qualified and experienced contractors to undertake asphalt resurfacing works at five locations on the Olympic Highway and Burley Griffin Way. The works are to be carried out in accordance with the tender specifications and associated contract documentation. - SITE INSPECTION AND BRIEFING MEETING The Tenderer must familiarise with the Works and the Site prior to submission of its tender. A Man
Asphalt resurfacing works at five locations on the Olympic Highway and Burley Griffin Way Asphalt resurfacing works at five locations, heavy duty dense graded asphalt, cold milling of road pavement materials, traffic management, construction surveys, quality management
AI helper
Tenders from qualified contractors for asphalt resurfacing at five locations on Olympic Highway and Burley Griffin Way. Mandatory pre-tender meeting and site inspection on 21 October 2026 at 10am, commencing at Dirnaseer Road stockpile site. Tenders close 6 November 2026. Works per TfNSW specifications including R116 heavy duty dense graded asphalt. Queries via Vendor Panel platform.
A mandatory pre-tender meeting and site inspections will be held as per below: date Wednesday 21 October 2026 time 10am location commence at location 1. Initial meeting will be at the Dirnaseer Road stockpile site just south of the work area.
RFT2027/8 Cootamundra STP Sludge Dewatering - Cootamundra- Gundagai Regional Council is seeking tenders from suitably qualified and experienced contractors for the provision of sludge dewatering services at the Cootamundra Sewage Treatment Plant. The services are required to support the ongoing operation and management of Council' s wastewater treatment infrastructure. Tenderers are invited to submit proposals in accordance with the requirements detailed in the tender documentation. - The Tenderer must fam
Provision of sludge dewatering services at the Cootamundra Sewage Treatment Plant Sludge dewatering services, dewatering of sludge from pond 1, design of dewatering process and equipment selection, dewatering of sludge to less than 75% moisture
AI helper
Provision of sludge dewatering services at Cootamundra STP. Mandatory site inspection on 3 November 2026. Tender closes 19 November 2026. Completion within 16 calendar weeks. Liquidated damages $1000/day. Retention 4% or undertaking. Monthly payment claims. Professional indemnity insurance required.
The time for completion is 16 calendar weeks after acceptance of tender. the time for completion is: 16 calendar weeks after the date of acceptance of the tender.
Payment claims are made monthly, on and after the last business day of each calendar month. payment claims are to be made: monthly, on and after the last business day of each calendar month.
Tenderers must be suitably qualified and experienced contractors. seeking tenders from suitably qualified and experienced contractors for the provision of sludge dewatering services.
Liquidated damages are **** per day for late completion. the rate per day for liquidated damages is: ****
A mandatory site inspection will be held on 3 November 2026 at 1:30 PM. a mandatory site inspection will be held as per the details provided in the table below date: tuesday 3 november 2026 time: 1:30 pm
Disputes must be notified within 10 business days after the act or omission. within 10 business days after: a the act or omission or b the expiry of a relevant period specified under clause **** or clause 15. 3
Failure to attend the mandatory site inspection may affect eligibility. a mandatory site inspection will be held as per the details provided in the table below
RFT2027/5 Sewer Mains Maintenance ( Cootamundra) - Cootamundra- Gundagai Regional Council is seeking tenders from suitably qualified and experienced contractors for the provision of sewer mains maintenance services within Cootamundra. The services are required to support the ongoing operation, maintenance and reliability of Council' s sewer infrastructure network. Tenderers are invited to submit proposals in accordance with the tender documentation. - The Tenderer must familiarise with the Works and the Si
Provision of sewer mains maintenance services within Cootamundra sewer mains maintenance cleaning, root cutting, CCTV inspection and smoke testing
AI helper
Tender for sewer mains maintenance services in Cootamundra, NSW. Services include cleaning, root cutting, CCTV inspection and smoke testing. Tender closes 17 November 2026. No mandatory site inspection. Questions via Vendor Panel platform by 10 November 2026. Contract period 30 calendar weeks. Liquidated damages **** per day. Retention 4% via bank guarantee. Payment claims monthly.
The time for completion is 30 calendar weeks after the date of acceptance of the tender. the time for completion is: 30 calendar weeks after the date of acceptance of the tender.
Payment claims are made monthly, on and after the 25th day of each calendar month. a payment claim is to be made: monthly, on and after 25th day of each calendar month.
Tenderers must be suitably qualified and experienced contractors. seeking tenders from suitably qualified and experienced contractors for the provision of sewer mains maintenance services.
Liquidated damages are **** per day for late completion. the rate per day for liquidated damages is: ****
No mandatory site inspection will be held. no mandatory site inspection will be held for this tender.
**** Installation of Seven Culverts - Cootamundra- Gundagai Regional Council is seeking quotations from suitably qualified contractors for culvert replacement works at various locations within the Local Government Area. The works include excavation of existing culverts, installation of new culvert pipes and associated road restoration works. Further details are provided within the RFQ documentation. - Site Meeting A site meeting will be held: Time - 10: 00am Date - Wednesday 4 November 2026 Location
Installation of seven culverts - culvert replacement works at various locations within the local government area Excavation of existing culverts, installation of new culvert pipes, road restoration works, disposal of waste to cootamundra waste facility
AI helper
Council seeks quotations for culvert replacement works at various locations. Works include excavation, installation of new culvert pipes, and road restoration. Site meeting on 4 November 2026 at 10:00am at No 4 stockpile site, Olympic Highway. Closing date: 13 November 2026 at 5:00pm. Evaluation criteria: price 50%, history/performance 10%, availability 20%, quality accreditations 20%. Contract term to 30 June 2027. Works scheduled February to 30 June 2027. Must have ABN and be GST registered. Submit electronically via Vendor Panel.
Works are scheduled to take place between February to 30 June 2027, as stated: works scheduled to take place between february to 30 june 2027 and will be planned in conjunction with successful contractor.
The evaluation criteria include price at 50%, history or performance at 10%, availability at 20%, and quality accreditations at 20%, as stated: a price 50. b history or performance with cootamundragundagai regional council 10. c availability 20. d quality accreditationscertificates of conformance to tfnsw r11 20.
Respondents must have an ABN and be registered for GST, as stated: cootamundragundagai regional council will not enter into an agreement with a company that does not have an australian business number and is not registered for gst.
A site meeting will be held on Wednesday 4 November 2026 at 10:00am, as stated: a site meeting will be held: time - 10: 00am date - wednesday 4 november 2026 location - request for quotation ****.
Submissions that do not include a fully completed response or contain corrupt files may be excluded, as stated: submissions that do not include a fully completed response. . . or electronic quotations that cannot be effectively evaluated because the file has become corrupt, may be excluded from the evaluation process without further consideration.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
