Landscaping Works - Minor and Medium Works Panel - Council intends to appoint multiple contractors to the panel. Appointment to the panel does not guarantee any minimum volume or value of work. Panel contractors may be invited to submit quotations for individual work packages that may include, but are not limited to: o Landscape construction and refurbishment works; o Park and open space improvements; o Streetscape enhancement projects; o Planting, turfing and revegetation works; o Irrigation installation a
Establishment of a panel of landscaping contractors for minor and medium works Landscape construction and refurbishment works, park and open space improvements, streetscape enhancement projects, planting turfing and revegetation works, irrigation installation and modifications, retaining walls and minor civil works, pathway construction, garden bed establishment and renewal, environmental rehabilitation and restoration projects, ancillary works
AI helper
Ipswich City Council seeks to establish a panel of landscaping contractors for minor and medium works across council-owned assets. Contract term is 3 years with options to extend up to 7 years. Tenders must be lodged via the vendor panel portal by 2pm on 17 November 2026. No minimum volume of work is guaranteed. Pricing for individual projects will be sought through RFQ processes. Evaluation criteria include company experience, personnel, methodology, capacity, local economic contribution, and past performance. No site visit is scheduled.
Tenders must be lodged by the closing time of 2pm on 17 November 2026. The RFT states: closing time: 2pm, 17 nov 2026.
Tenderers must demonstrate landscaping construction experience and hold relevant licences. The RFT states: hold relevant licences and registrations and demonstrate landscaping construction experience.
No site visit is scheduled. The RFT states: visit to council site clause 5. 3 not applicable.
The last day for clarification requests is 13 November 2026. The RFT states: last day for clarification requests 13 nov. 2026.
Tenders may be rejected if non-conforming or late. The RFT states: a tender. . . where lodgement did not occur by the closing time. . . may be treated as nonconforming and rejected.
Jack Cooper Reserve Playspace - The project, located at Hibbard Dr Hillier, includes the construction and delivery of a new playspace and irrigation along with minor earthworks. The project includes the installation of proprietary play equipment, nature play elements such as a waterplay creek and sandpit, rockwork, new furniture, hardstand and softfall surfacing, a shade sail, and associated landscaping, including new turf, irrigation connected to the existing system, trees and garden beds. A site briefing
Construction and delivery of a new playspace and irrigation at Jack Cooper Reserve, including minor earthworks Installation of proprietary play equipment, nature play elements such as waterplay creek and sandpit, rockwork, new furniture, hardstand and softfall surfacing, shade sail, landscaping including turf, irrigation connected to existing system, trees and garden beds
AI helper
Tender for construction of Jack Cooper Reserve playspace in Hillier, SA. Includes play equipment, waterplay creek, sandpit, landscaping, irrigation, shade sail, and earthworks. Tenders due 25 Nov 2026 via VendorPanel. Optional site briefing on 9 Nov 2026. Evaluation uses weighted criteria including price, experience, WHS, and local economic benefit. Various management plans and safety inspections required.
The project is expected to be completed within the **** financial year. Commencement of works is indicative for Monday 11th January 2027. ensure the project is completed within the **** financial year and on budget
The evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be considered. the evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be considered in the selection of a preferred tenderer
Tenderers must be licensed or registered to perform the works. each tenderer must if applicable be licensed or registered to perform the works
An optional informal briefing session is to be conducted on 10am Adelaide time, Monday 9th November 2026 at Jack Cooper Reserve. an optional informal briefing session is to be conducted on 10am adelaide time, monday 9th november 2026 jack cooper reserve, hibbard drive, hillier sa ****
Tenders received after the closing date will not be considered. tenders received after the closing date will not be considered or accepted
Tree Planting/ Playground Equipment Supply/ Playground Equipment Supply And Installation/ Park Furniture Supply
MRC 2027 COCC **** Muller Park Playground - Mackay Regional Council ( the Principal) invites tenders from suitably qualified and experienced contractors for the construction of the Muller Park Playground Renewal project, Contract No. MRC 2027 COCC**** Muller Park Playground, as described. The Works comprise the construction of a new playground facility at Muller Park, Ooralea, including the installation of playground equipment, artificial soft- fall surfacing, a shade structure, playground safety fencin
Construction of the Muller Park Playground renewal project Playground equipment installation, artificial softfall surfacing, shade structure, playground safety fencing and gates, concrete footpaths, drainage works, park furniture, landscaping, tree planting, associated civil and ancillary works
AI helper
Mackay Regional Council invites tenders for construction of Muller Park Playground renewal. Works include playground equipment, softfall surfacing, shade structure, fencing, footpaths, drainage, furniture, landscaping. Lump sum contract with priced BOQ. Commencement 1 March 2027, completion 30 June 2027. Tenders due 27 November 2026 1pm via VendorPanel. Evaluation criteria: relevant experience 20%, key personnel 20%, resources 10%, methodology 20%, value for money 30%. Tenders valid 90 days. Complaints to complaints@mackay. qld. gov. au.
The works are proposed to commence on 1 March 2027 and be completed by 30 June 2027. The works are proposed to commence on 1 march 2027 and be completed by 30 june 2027.
The evaluation criteria include value for money with a weighting of 30. value for money 30 as per attached pricing schedule
Tenderers must be suitably qualified and experienced contractors. invites tenders from suitably qualified and experienced contractors for the construction of the muller park playground renewal project
Communications regarding the procurement process must be submitted no later than 3 calendar days prior to the time stated in item 4. must be submitted to tenderers: ***@***. *. * no later than 3 calendar days prior to the time stated in item 4
**** - Dunn Park Living Wetland - As per the Request for Tender documents.
Drainage and earthworks for rehabilitation and enhancement of an existing stormwater attenuation basin at Dunn Park Living Wetland Traffic management and site- specific safety management plans, site establishment including fencing and environmental controls, protection of retained vegetation, removal and disposal of existing drainage infrastructure, removal and disposal of environmental weeds, stripping stockpiling and management of topsoil, bulk earthworks including excavation trimming and shaping, overexcavation of planting areas, cultivation of subgrade, placement of topsoil and growing medium, supply and installation of drainage structures, supply and installation of rock armouring geocellular confinement systems and split pea gravel mulch, removal and disposal of surplus spoil, site cleanup and demobilisation, as- constructed survey
AI helper
City of Albany seeks a qualified contractor for drainage and earthworks to rehabilitate an existing stormwater attenuation basin at Dunn Park, Orana, Albany. Works include bulk earthworks, drainage structures, rock armouring, geoweb, and topsoil placement. Excludes planting and jute matting. Site works from 1 February 2027 to 30 April 2027. Tender deadline 25 November 2026, 10:00 AM AWST. Submit via VendorPanel or tender box. Price on schedule of rates, fixed for contract term. Liquidated damages AUD 500 per day. Public liability insurance AUD 20 million required. Optional site meeting available upon request. Best value for money evaluation.
Works must be completed by 30 April 2027. The contractor shall plan and sequence the works to achieve practical completion within this period. practical completion shall be achieved no later than 30 april 2027
Prices tendered are on a schedule of rates basis, fixed for the contract term, and must include GST. prices tendered are to be on a schedule of rates basis. all prices for goods and/or services are to be fixed for the term of the contract.
The principal has adopted a best value for money approach. the offer containing the lowest price will not necessarily be accepted.
Offers are assessed against selection criteria and scored. offers are assessed against the responses to the selection criteria and shall be scored in accordance with the following table
Liquidated damages of AUD 500 per day apply if practical completion is not achieved by the specified date. liquidated damages of 500 ex. gst per day will apply.
There is no mandatory site inspection, but a site meeting may be arranged upon request. there isn't a mandatory tender briefing/site inspection however a site meeting with a city of albany representative may be arranged upon request.
Offers that do not contain all information requested as per selection criteria will be excluded from evaluation. offers that do not contain all information requested as per selection criteria will be excluded from evaluation.
**** Caloundra Headland Coastal Pathway and Civil Works - Section B - Sunshine Coast Council is seeking a suitably qualified Principal Contractor to construct a section of coastal pathway along the Esplanade Headland, Kings Beach. The section of pathway stretches approximately 200 linear metres and comprises of a concrete pathway, retaining walls and car park works. The scope of work includes, but is not limited to: o Concrete pathway construction; o Drainage construction; o Landscape works ( hardscape,
Construction of a section of coastal pathway along the Esplanade Headland, Kings Beach, including concrete pathway, retaining walls and car park works Concrete pathway construction, drainage construction, landscape works ( hardscape, furniture installation and planting), lighting and electrical work, installation of memorial plaques, traffic and pedestrian management, site management including environmental and WHS, subcontractor management, maintenance and defects liability period
AI helper
Sunshine Coast Council seeks a principal contractor for a coastal pathway section at Kings Beach, approximately 200 linear metres, including concrete pathway, retaining walls, car park, drainage, landscape, lighting, and electrical works. Lump sum contract, commencement early February 2027, functional completion by 30 June 2027. Tenders due 12noon 27 October 2026 (website shows 2 November 2026). Site information session on 8 October 2026 at Centaur Park carpark, registration required via email. Evaluation criteria: price 35%, capability and experience 25%, methodology 20%, social and economic factors 20%. Tenders submitted electronically via VendorPanel. Clarification cutoff 3 business days before closing.
Functional completion is required by 30 June 2027, as stated: functional completion required by 30 june 2027.
The evaluation criteria include price at 35% weighting, as stated: price 35.
A site information session will be held on 8 October 2026 at Centaur Park carpark, as stated: site information session will be held in accordance with the details provided in schedule 2.
Clarification cutoff is 3 business days prior to closing date, as stated: clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.
Prohibited contact with council employees or elected members may lead to disqualification, as stated: any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
