Shade Removal Tenders

The completion date for the project is April 30th, 2027.

Payments for progress claims are made by the end of each month.

The certificate shall be issued to contractor pursuant to clause 34. 6 of the as **** general conditions of contract **** subject to the contractor providing asbuilt documentation and warranties.

The general assessment criteria used are capability, methodology, price, organisational capacity, experience, and sustainability.

Respondents must provide a brief history, size, corporate structure, HSR/safety officer details, and any relevant accreditations.

Liquidated damages are 750 per day.

Attendance of briefing is compulsory to complete a compliant submission to this tender opportunity.

A site visit will be held at Thornlie TAFe Campus, Burslem Drive, Thornlie, **** on 27 Aug, 2026 11:00 am. a site visit will be held at thornlie tafe campus,, burslem drive,, thornlie, **** on 27 aug, 2026 11: 00 am.

The project must be completed by Friday, 29 May 2027, to meet existing funding agreement conditions. his project in its entirety is to be completed before friday the 29th may 2027 to enable rcc to meet existing funding agreement conditions.

Tenders will be evaluated based on weighted criteria including local business and benefit (15%), tendered sum (35%), experience and operational capability (30%), and program of works/commissioning program (20%). he weighted criteria will be assessed and considered as part of the weighting tender evaluation process.

Tenderers must have the necessary skills, knowledge, and experience to provide the goods and/or services sought. They must have fully examined the ITT and made their own enquiries to inform themselves of all risks and circumstances. he necessary skills, knowledge, and experience to provide the goods andor services sought

An inspection of the site is highly recommended to assist tenderers in preparing their tenders. o assist tenderers in preparing their tenders, an inspection of the site is highly recommended.

The method of lodgement of samples is not applicable. ot applicable.

Tenders may be classified as non-conforming and excluded from further consideration if they do not comply with the full requirements of the ITT or propose to engage a dismissed employee. enders may be classified as nonconforming and excluded from further consideration if: a a tender does not comply with the full requirements of this itt

The bid notice states that the time for completion is 20 weeks. ime for completionclause 23 conditions of contract 20 weeks

The bid notice states that the basis of payment is lump sum. basis of paymentclause 3. 1 conditions of contract lump sum

The bid notice states that the defects liability period is 52 weeks. defects liability periodclause 43 conditions of contract 52 weeks

The bid notice states that the assessment criteria include price, past performance, local content, timeliness, and capacity. assessment criteria weightingsclause 19 conditions of quoting price 30past performance 20local content 30timeliness 10capacity 10total 100

The bid notice states that where building works require a current builders registration, the works must be carried out by a registered builder. builders registrationwhere building works require a current builders registration, the works must be carried out by a registered builder in one of the following categories: building contractor commercial restricted

The bid notice states that a site inspection is scheduled for March 9, 2026, at 10:00 AM. site inspectionclause 4 conditions of quoting yesset timecontact chrisovalandis mastorostelephone 08 **** **** wulagi primary school then middle point afterwards designated timeday 10: 00 on the 9 march 2026