Cann Valley Fire Station - Alterations & Additions - To seek tenders from suitable building contractors to construct Alterations and Additions to the Cann Valley Fire Station. Scope includes: Construction of Extension to existing Cann Valley Fire Station to include BA Washroom, Turnout Room with Change Cubicle and Multi Purpose Room with Kitchenette. Replacement of existing Manual Motor Room Door with motorised sectional panel lift door. Reconfiguration and Internal Refurbishment to include Toilet, Accessib
AI helper
Fixed price lump sum contract for alterations and additions to Cann Valley Fire Station. Scope includes extension, refurbishment, new shed, driveway and stand pipe. Tenders must be lodged electronically via www. ***. *. * by 2:00 PM on 13 November 2026. Site inspections are available on 15, 19 and 28 October 2026, registration required. Evaluation criteria: experience and capability 40%, resource capacity 40%, program 15%, social and environmental benefits 5%, OHS compliance mandatory, price lowest acceptable tender. Completion within 100 working days, latest date 30 June 2027. Tender validity 60 days.
The latest date for completion of the works is 30th June 2027. The principals nominated period for completion is 100 working days. the latest date for completion of the works is 30th june 2027
The evaluation criteria include non-price criteria and price. The price criterion is lowest acceptable tender. price lowest acceptable tender
Tenderers must complete the OHS questionnaire and may need to provide evidence of certification or complete the assessment checklist. the tenderer shall attach a copy of any documentation evidencing certification of their individual enterprise by a recognised independent authority
Site inspections are held on 15, 19 and 28 October 2026. Registration is required via the briefing section on www. ***. *. * site inspection is being held between **** am and **** pm thursday 15 october 2026
Tenders not complying with requirements may be rejected. Late submissions will not be accepted. any tender that does not comply with any requirement of the tender documents or contains provisions in conflict with the tender documents may be rejected
Cann Valley Fire Station - Alterations & Additions - To seek tenders from suitable building contractors to construct Alterations and Additions to the Cann Valley Fire Station. Scope includes: Construction of Extension to existing Cann Valley Fire Station to include BA Washroom, Turnout Room with Change Cubicle and Multi Purpose Room with Kitchenette. Replacement of existing Manual Motor Room Door with motorised sectional panel lift door. Reconfiguration and Internal Refurbishment to include Toilet, Accessib
AI helper
Fixed price lump sum contract for alterations and additions to Cann Valley Fire Station. Tenders due 4 November 2026, 2:00 PM via www. ***. *. * within 100 working days, latest date 30 June 2027. Evaluation criteria: experience and capability 40%, resource capacity 40%, program 15%, social and environmental benefits 5%, OHS compliance mandatory, price lowest acceptable tender. Site inspection to be requested via Buying for Victoria website. Tender validity 60 days. Insurance required. Victorian Government caretaker conventions apply from 3 November 2026.
The latest date for completion of the works is 30th June 2027. The principals nominated period for completion is 100 working days. The latest date for completion of the works is 30th june 2027.
The evaluation criteria include non-price criteria and price. price lowest acceptable tender.
Tenderers must complete the OHS questionnaire and may need to provide evidence of certification. does the company have an ohs management system certified by a recognised independent authority
Tenderers are required to inspect the site prior to submitting tenders. tenderers are required to acquaint themselves with all matters relating to the proposed contract and to inspect the site and existing conditions prior to submitting their tenders.
Tenders not complying with requirements may be rejected. any tender that does not comply with any requirement of the tender documents or contains provisions in conflict with the tender documents may be rejected.
Real Festival 2026_ Event Infrastructure - Real Festival is Penrith City Council s annual flagship event, delivered at Tench Reserve along the Nepean River. The festival will be held on 11, 12 and 13 September 2026, bringing the community together to celebrate creativity, culture, sustainability, and the unique river environment that defines the region. As Penrith s largest family- focused event, Real Festival attracts thousands of visitors across its three- day program and features art installations, live
Event infrastructure for Real Festival 2026 and 2027 Supply, installation, servicing, and packdown of event structures, equipment, furnishings, crowd management solutions, and associated infrastructure. This includes site sheds, offices, parents room, toilets ( accessible and portable), handwash basins, temporary fencing, crowd control barriers, triton/waterfill barriers, scrim, buggy forks, knuckleboom lift, all- terrain scissor lifts, baby change tables, full- length mirrors, balloon lighting towers, and VMS boards.
AI helper
Penrith City Council is seeking a supplier for comprehensive event infrastructure for Real Festival 2026 and 2027. The scope includes supply, installation, servicing, and packdown of various event structures and equipment. The contract is for a two-year period. Respondents must submit a rates card and pricing for 2026, with an indicative estimate for 2027. A final walkthrough with the council's project lead is required. After-hours support and waste removal are also specified. References from similar projects are mandatory.
Bump in for infrastructure is scheduled for Tuesday 8 September 2026, with event readiness by 12:00 PM on Friday 11 September 2026. Bump out is scheduled for Monday 14 September 2026.
Suppliers must be suitably qualified and experienced, and submit two recent references from clients for whom they have completed work of a similar scale, scope, and operational requirements.
A site recce is recommended to confirm requirements, as event elements are subject to change. A final walkthrough with the council's project lead is mandatory.
Supplier query cutoff is Sunday 31 May 2026 at 11:00 PM E. South America Standard Time.
Real Festival 2026_ Event Infrastructure - Real Festival is Penrith City Council s annual flagship event, delivered at Tench Reserve along the Nepean River. The festival will be held on 11, 12 and 13 September 2026, bringing the community together to celebrate creativity, culture, sustainability, and the unique river environment that defines the region. As Penrith s largest family- focused event, Real Festival attracts thousands of visitors across its three- day program and features art installations, live
Event infrastructure for Real Festival 2026 and 2027 Supply, installation, servicing, and packdown of event structures, equipment, furnishings, crowd management solutions, and associated infrastructure. This includes site sheds, offices, parent' s room, toilets ( accessible and portable), handwash basins, temporary fencing, crowd control barriers, triton/waterfill barriers, scrim, buggy forks, knuckleboom lift, all- terrain scissor lifts, baby change tables, full- length mirrors, balloon lighting towers, and VMS boards.
AI helper
Penrith City Council is seeking a supplier for comprehensive event infrastructure for Real Festival 2026 and 2027. The scope includes supply, installation, servicing, and packdown of various event structures and equipment. The contract is for a two-year period. Respondents must submit a rates card and pricing for 2026, with an indicative estimate for 2027. The festival dates for 2026 are September **** site recce is recommended as event elements are subject to change. The successful respondent will be engaged for two years, subject to satisfactory performance. Faulty equipment must be immediately replaced, and after-hours support is required.
The event is scheduled for September 11, 12, and 13, 2026. Bump-in for infrastructure is scheduled for Tuesday, September 8, 2026, and bump-out is scheduled for Monday, September 14, 2026.
Suppliers are required to be suitably qualified and experienced and must provide wo recent references from clients for whom they have completed work of a similar scale, scope, and operational requirements.
A site recce is recommended to confirm requirements, as event elements are subject to change.
The supplier query cutoff is Sunday, May 31, 2026, 11:00 pm E. South America Standard Time.
Real Festival 2026_ Event Infrastructure - Real Festival is Penrith City Council s annual flagship event, delivered at Tench Reserve along the Nepean River. The festival will be held on 11, 12 and 13 September 2026, bringing the community together to celebrate creativity, culture, sustainability, and the unique river environment that defines the region. As Penrith s largest family- focused event, Real Festival attracts thousands of visitors across its three- day program and features art installations, live
Comprehensive event infrastructure for Real Festival 2026 and 2027. Site sheds ( approx. 3), toilet facilities ( including accessible and portaloos), water infrastructure, fencing ( temporary and crowd control barriers), plant access equipment ( buggy forks, knuckleboom lift, scissor lifts), baby change tables, full- length mirrors, balloon lighting towers, VMS boards, and associated staffing/labour for installation and packdown.
AI helper
Penrith City Council is seeking a supplier for comprehensive event infrastructure for the Real Festival in 2026 and 2027. The scope includes the supply, installation, servicing, and packdown of various event structures and equipment such as site sheds, toilets, fencing, lighting, and VMS boards. The successful respondent will be engaged under a two-year arrangement. Respondents are required to submit a rates card and pricing for 2026 and an indicative pricing estimate for 2027. The event is scheduled for September ****, 2026. Key requirements include providing event-ready equipment, performing a final site walkthrough, immediately replacing faulty equipment, and providing after-hours support. Two recent references from clients for similar-scale projects are also required.
The event is scheduled to be held on September 11, 12, and 13, 2026. Specific bump-in and bump-out timings are detailed in the projected timings scope, with bump-in commencing on Tuesday, September 8, 2026, and bump-out on Monday, September 14, 2026.
The supplier must be suitably qualified and experienced to provide comprehensive event infrastructure, and must submit two recent references from clients for whom they have completed work of a similar scale, scope, and operational requirements.
The notice mentions that draft site maps are attached for reference and that event elements are subject to change and require a site recce to confirm requirements, implying a site visit may be necessary.
The supplier query cutoff date is Sunday, 31 May 2026, 11:00 pm E. South America Standard Time.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Plans start at A$ 30.00/month, with options for different needs and subscription terms. Plans are prepaid: check the total amount and duration before confirming. Start with the free trial and assess the results before subscribing, with no automatic charges.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
