Tenders at Thursday Island, QLD

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

All work must be carried out by experienced and licensed personnel in the field of work specified.

if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.

Quotations must be lodged by the close date: close date: 13th november 2026 @2pm.

Payment is made within 30 days of receiving a valid tax invoice: the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice.

The contractor warrants the works will be free from any charge, liability or defect and fit for purpose and conform to the description ordered.

Award is based on best value for money: the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

All work must be carried out by experienced and licensed personnel: all work must be carried out by experienced and licensed personnel in the field of work specified.

If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

If the quotation form and response schedules are not completed, the rfq will be classed as non- conforming ( items 7. 1 through to 7. 8).

Quotations must be lodged by the close date: 13th November 2026 @2pm. close date: 13th november 2026 @2pm

Payment is lump sum on completion, with progress claims considered upon request. basis of payment lump sum on completion progress claims will be considered upon request

The contractor warrants the works are free from defects, comply with standards, and are fit for purpose. the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose

Best value for money, assessing quoted price and non-price criteria. awarded to the respondent who best demonstrates the ability to provide best value for money

All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified

If works are not completed within the requested timeframe, TSIRC may remove the work order. tsirc nominated representatives have the authority to remove the system work order from the contractor

RFQ will be non-conforming if the 7. 3 lump sum price breakdown schedule is amended or quotation form not completed. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non-conforming

Quotations must be lodged by 16th November 2026 @2pm. The closing date is stated as close date: 16th november 2026 @2pm.

Payment is lump sum on completion, with progress claims considered upon request. The contractor will be paid within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice.

The contractor warrants the works will be free from defects, comply with standards, and be fit for purpose. the contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect.

The engagement shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome.

All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified.

If works are not completed within the requested timeframe, TSIRC may remove the work order and undertake work by other means. tsirc nominated representatives have the authority to remove the system work order from the contractor.

If the quotation form and response schedules are not completed, the RFQ will be classed as non-conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming.

Quotations must be lodged by the close date: close date: 18th november 2026 @2pm.

Payment is lump sum on completion with progress claims will be considered upon request. Payment within 30 days of receiving a valid tax invoice.

Defect liability period is 12 months from completion date. Contractor must remedy defects within 30 days of notification at no additional cost.

Awarded to respondent who best demonstrates the ability to provide best value for money. Criteria: tender price 45%, local content 15%, quality 15%, WHS 10%, timeliness 15%.

All work must be carried out by experienced and licensed personnel in the field of work specified. Contractors must obtain all necessary permits and comply with local council rules.

If works not completed within requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

RFQ will be classed as non-conforming if the lump sum price breakdown schedule is amended or if quotation form and response schedules are not completed.