Flooring Tenders

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. please complete 7. 3 lump sum price breakdown schedule if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.

Practical completion of the works must be completed on or before 11 December 2026. Practical completion of the works must be completed on or before 11 december 2026.

Payments made under a contract awarded from this tender will be monthly in arrears. the successful contractor accepts that payments made under a contract awarded from this tender will be monthly in arrears.

The contractor must warrant that it complies with, and will continue to comply with, the queensland government supplier code of conduct. does the contractor warrant that it complies with, and will continue to comply with, the queensland government supplier code of conduct

The evaluation criteria include value for money, demonstrated ability to deliver methodology and achieve project program, proposed timeline, and demonstrated understanding and experience in delivering similar projects. weighted criteria 1. value for money

Mandatory criteria include demonstrated holding of current mandatory licenses and attendance to the tender site inspection. mandatory criteria 1. demonstrated holding of current mandatory licenses 1. attendance to the tender site inspection

Attendance at the tender site inspection session is mandatory, and nonattendance will result in a nonconforming tender submission. important: 1. attendance at the tender site inspection session is mandatory.

Failure to attend the mandatory site inspection will result in a nonconforming tender submission. nonattendance will result in a nonconforming tender submission.

A date and time for a mandatory site walkthrough has been arranged and is documented in section 1. 4. a date and time for a mandatory site walkthrough has been arranged and is documented in section 1. 4.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered. the contractor warrants that, when title of the works passes to tsirc, the works will:

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

If works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means. if works are not completed within the requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.