Statement Work Tenders

The works must be completed within twelve weeks of possession of site, with practical completion by 30 June 2027. As stated: the whole of the works shall be completed within twelve weeks of possession of site.

Progress claims are issued monthly upon completion of project stages. As stated: to be issued monthly issued on completion of stage claim to be submitted upon progress claims.

Defects liability period is 12 months from practical completion. As stated: defects liability period 12 months from practical completion.

The contract is awarded based on best value for money, considering qualitative criteria and price. As stated: the principal has adopted the best value for money approach to this request.

Tenderers must provide evidence of insurance coverage, financial statements, and relevant licenses. As stated: tenderers must supply evidence of their insurance coverage including, insurer, expiry date, value, and type of insurance.

Liquidated damages are set at $400 per day for late completion. As stated: liquidated damages rate based on potential losses associated with late completion 400 day.

Site inspection is optional but recommended. As stated: attendance at a site meeting is not mandatory. a site inspection is advantageous.

Responses may be rejected if submitted after the deadline, not at the specified place, or missing required attachments. As stated: a response may be rejected without consideration of its merits if: a it is submitted after the deadline.

The whole of the works shall be completed within twelve weeks of possession of site, subject to water availability and any agreed changes approved by the principals representative.

Defects liability period 12 months from practical completion.

The principal has adopted the best value for money approach to this request. This means that, although price is considered, the response containing the lowest price will not necessarily be accepted.

Tenderers are to provide copies of their drivers licences and/or operators tickets and traffic management qualifications.

Liquidated damages rate based on potential losses associated with late completion 400 day.

Attendance at a site meeting is not mandatory. A site inspection is advantageous as it will provide respondents with the opportunity to clarify any uncertainties with the contact person prior to the closing of the request for tender.

A response may be rejected without consideration of its merits if it is submitted after the deadline, it is not submitted at the place specified in the request for tender, or the tender does not submit an offer form which has been completed and signed together with all required attachments.

Contract ends Friday, 19 March 2027. Deliverables like the WA Certificate of Electrical Safety are due on completion of project.

Payment at 100% of contract price upon practical completion and successful handover. No progress or advance payments will be made.

Best value for money. The successful supplier will have demonstrated its ability to provide the best value for the customer. This will not necessarily be the lowest price.

Must be an Australian business. The supplier must ensure that they are an Australian business for the purpose of paragraph 5. 4 of the commonwealth procurement rules.

No site inspections. Unless otherwise notified by an addendum, there are no site inspections for this atm.

Questions permitted until 5:00 pm Monday, 9 November 2026.

Failure to comply with minimum content and format requirements means your response cannot be considered. Also, non-compliance with the Commonwealth Contract Terms is non-negotiable.

Estimated value is from $50,**** to $50,**** AUD.