Texas STP upgrade Pond works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Maturation Pond 1 Package and includes the construction, testing, commissioning of a Pond and associated infrastructure, as detailed in the Contract Documents.
construction, testing and commissioning of a maturation pond and associated infrastructure mobilisation, pond construction, geomembrane liner, weirs, drainage pump station, mixer installations, pipework, electrical conduits, testing & commissioning, closeout
AI helper
Construction of Maturation Pond 1 for the Texas wastewater treatment plant upgrade. Tender closes 4 Nov 2026. Lump sum contract, single delivery location. Evaluation on price, past performance, technical expertise, WHS, availability, local contractor. Optional site visit. 12?month workmanship warranty. Completion by 17 Dec **** tender validity.
completion of all components of the works, including commissioning, is required by 17 December 2027.
progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.
contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
the contractor is responsible for and warrants that it has: . . . the necessary skills and expertise to be able to competently supply the scope of works.
there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time.
any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
Texas STP upgrade Civil & Mechanical works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Civil and Mechanical Works Package and includes the construction, installation, testing, commissioning support and closeout of the civil and mechanical works associated with the project a
Texas wastewater treatment plant upgrade civil and mechanical works Construction, installation, testing, commissioning, and closeout of civil and mechanical works for Texas wastewater treatment plant upgrade, including mobilisation, surveying, lagoon works, pipework, pump station construction, electrical conduits, roadworks, traffic management, and related services.
AI helper
Supplier must submit a lump sum tender for civil and mechanical works at Texas WWTP, due 4pm 4 Nov 2026. Evaluation considers price, past performance, technical expertise, WHS, availability, and local contractor. Optional site visit available; no mandatory samples. Single delivery location; 12?month workmanship warranty.
closing time of 4pm est, Wednesday 4th November 2026
12 months warranty on all workmanship from the date of the practical completion inspection.
submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor
necessary skills and expertise to be able to competently supply the scope of works.
there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.
supplier query cutoff Wednesday 4th November 2026 03:00 am e. south america standard time
any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification
Texas STP upgrade Civil & Mechanical works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Civil and Mechanical Works Package and includes the construction, installation, testing, commissioning support and closeout of the civil and mechanical works associated with the project a
civil and mechanical works package construction, installation, testing, commissioning, closeout of civil and mechanical works including mobilisation, survey, lagoon works, pipework, pump station, building interfaces, site pipework, electrical conduits, roadworks, traffic management, and related site works.
AI helper
Goondiwindi Regional Council invites bids for a civil and mechanical works package to upgrade the Texas wastewater treatment plant. The contract is lump sum, with a single delivery location. Bids must be lodged by 4pm EST on 4 November 2026. Evaluation considers price, past performance, technical expertise, WHS, availability, and local contractor status. No mandatory site visit; optional visits are welcome. No samples required.
submissions shall be lodged on or before the closing time of 4pm est, wednesday 4th november 2026.
the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
the respondent is responsible for and warrants that it has . . . necessary skills and expertise to be able to competently supply the scope of works.
there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.
supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time
any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
Acacia Prison Expansion Project - Wastewater Treatment Plant - - The Office of Major Infrastructure Delivery ( OMID), on behalf od of the Department of Justice is seeking to procure a Single Stage, Design and Construct contract for the delivery of a new wastewater treatment plant ( WWTP) to service the Acacia Prison Expansion Works. The Acacia Prison Expansion Project ( APEP) will be located at Wooroloo in the Perth metropolitan area. Potential Respondents will need to submit a signed confidentiality docume
Texas STP upgrade Civil & Mechanical works package - Goondiwindi Regional Council is undertaking an upgrade of the Texas Wastewater Treatment Plant ( WWTP) to facilitate the disposal of treated effluent. The overall project comprises multiple packages of works to deliver the upgrade. This Tender relates specifically to the Civil and Mechanical Works Package and includes the construction, installation, testing, commissioning support and closeout of the civil and mechanical works associated with the project a
civil and mechanical works construction, installation, testing, commissioning, closeout of civil and mechanical works; mobilisation, survey, storage lagoon works, pipework decommissioning, new interlagoon pipework, effluent pump station building interfaces, sewer pump station installation, treatment plant building interfaces, service water package, site pipework, electrical conduits, roadworks, traffic management, quality records, as? constructed documentation, manuals
AI helper
Tender for civil and mechanical works package for Texas wastewater treatment plant upgrade. Lump sum contract, submission deadline ****, single site at Texas QLD. Evaluation on price, past performance, technical expertise, WHS, availability, local contractor. No mandatory site visit, optional. Contract completion by 17?Dec?2027. 12?month workmanship warranty.
closing time of 4pm est, Wednesday 4th November 2026
12 months warranty on all workmanship from the date of the practical completion inspection.
submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor
there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.
any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification
We selected helpful reviews from real users. Order may change periodically.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
Good information. All the information is very good!
J. A. Tellez
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
The platform is very user-friendly.
N. Lobato
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
A very good platform.
D. C. Espinosa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
Excellent information. Just what I was looking for.
L. H. Borrelli
They notify me promptly when a contest is published.
L. Salazar
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 32.50 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1107 active users, conducted through 21/10/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
