Supply, install, test and commission electrical works for Texas WWTP upgrade. Lump sum contract, GST inclusive. Completion by 17 December 2027. Tender closes 4pm EST, 4 November 2026. No mandatory site visit, but requests welcome. 12-month workmanship warranty. Retention: 10% of progress payments, 50% released at practical completion, 50% at end of defects liability period. Public liability insurance $20M, professional indemnity $2M. Submissions via Vendor Panel.
Completion of all works, including commissioning, is required by 17 December 2027. The contract states: completion of all components of the works, including commissioning, is required by 17 december 2027.
Progress claims may be submitted for works fully executed on site or materials delivered to site. The contract states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.
The contractor provides a 12-month warranty on all workmanship from practical completion. The contract states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
Submissions are assessed on multiple criteria including price, past performance, technical expertise, WHS systems, availability, and local contractor status. The document states: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
The works must be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor. The document states: the works shall be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor with the skills and resources necessary to complete the works safely.
Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.
There is no mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
Direct contact with council employees, councillors, or consultants is prohibited and will result in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
