Effluent Treatment Tenders

completion of all components of the works, including commissioning, is required by 17 December 2027.

progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

the contractor is responsible for and warrants that it has: . . . the necessary skills and expertise to be able to competently supply the scope of works.

there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time.

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

closing time of 4pm est, Wednesday 4th November 2026

12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor

necessary skills and expertise to be able to competently supply the scope of works.

there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

supplier query cutoff Wednesday 4th November 2026 03:00 am e. south america standard time

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification

completion of all components of the works, including commissioning, is required by 17 December 2027.

a portion of each progress payment, equivalent to 10 of the value of work completed exclusive of gst, shall be retained by council. . . 50 of the accumulated retention money shall be released upon practical completion. . . remaining 50 released at the expiry of the defects liability period 12 months.

contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

the contractor shall be a suitably qualified, experienced and appropriately licensed electrical contractor.

a portion of each progress payment, equivalent to 10 of the value of work completed exclusive of gst, shall be retained by council. . . 50 of the accumulated retention money shall be released upon practical completion. . . remaining 50 released at the expiry of the defects liability period 12 months.

there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

submissions shall be lodged on or before the closing time of 4pm est, wednesday 4th november 2026.

the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

the respondent is responsible for and warrants that it has . . . necessary skills and expertise to be able to competently supply the scope of works.

there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.