EOI for Callide Electorate Office Refurbishment ( Biloela, QLD) - QPS is seeking interest from qualified building companies to project manage and refurbish the Callide Electorate Office located at 64 Callide Street, Biloela Qld **** refer to the following documents for further details of this Expression of Interest ( EOI). If your company is interested in being involved in the Invitation to Tender ( ITO) phase for this refurbishment of the Callide Electorate Office, please submit a response to this
Refurbishment of the Callide electorate office Office fitout including partitions, ceilings, glazing, doors, floor coverings, painting, window coverings, workstations, loose furniture, joinery, air conditioning, electrical, telecommunications, security, MATV, fire services, signage, and relocation
AI helper
Expression of interest for qualified building companies to project manage and refurbish the Callide electorate office at 64 Callide Street, Biloela QLD 4715. The fitout must comply with relevant legislation, Australian standards, and the National Construction Code. Includes design and construction of partitions, ceilings, glazing, doors, floor coverings, painting, workstations, joinery, air conditioning, electrical, telecommunications, security, MATV, fire services, signage, and relocation of staff belongings. Responses due by 16 November 2026.
A minimum warranty period of 5 years is required on all parts and components for workstations and loose furniture, as stated: A minimum warranty period of 5 years is required on all parts and components.
CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
Design and construction of refurbishment works to Shop 11, meeting room, within the heritage Campbell' s Corner building Refurbishment works to Shop 11, meeting room, heritage building renovation, design and construction services
AI helper
Muswellbrook Shire Council seeks submissions for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** closes 19 November 2026. Working hours 7am-5pm Monday to Friday. Liquidated damages $100 per day. Defects liability period 12 months. Public liability insurance $20 million required. Security: bank guarantees each 2. 5% of contract sum. Payment claims by 28th day of each month. Indigenous participation target applies.
Payment claims are made progressively, with the principal paying the scheduled amount within 15 business days after receiving the claim. The contract states: the principal must pay the contractor the scheduled amount if any by the date that is 15 business days after the principals representatives receipt of the relevant payment claim.
The contractor warrants that all materials and equipment supplied will be new, fit for purpose, and comply with the National Construction Code. The contract states: all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code.
The contractor must be appropriately qualified and experienced. The contract states: seeking submissions from appropriately qualified and experienced respondents for the design and construction of the refurbishment works.
Liquidated damages of $100 per day apply for late completion. The contract states: liquidated damages will be due and payable to the principal by the contractor at the rate stated in item 17 which is $100 per day.
Failure to provide security within 3 business days after the contract date may result in default. The contract states: the contractor must, within 3 business days after the contract date, provide such guarantees to the principals representative.
PAH - Endoscopy Procedure Room Upgrade Project - This procurement seeks to engage a suitability qualified Principal Contractor to deliver the PAH Endoscopy Procedure Room Upgrade Project within the existing Endoscopy Department at Princess Alexandra Hospital including full design and construction. The works involve the refurbishment and reconfiguration of existing departmental spaces, including the conversion of the current Dirty Utility, Staff Toilet, and adjacent shell office area into a dedicated endosco
PAH Endoscopy Procedure Room Upgrade Project - design and construction of a dedicated endoscopy procedure room at Princess Alexandra Hospital Refurbishment and reconfiguration of existing departmental spaces, conversion of dirty utility, staff toilet, and shell office area into endoscopy procedure room, medical gases, electrical services, ICT and communication infrastructure, hydraulic services, mechanical services and HVAC modifications, nurse call and clinical systems, radiation shielding, fire services modifications, clinical infrastructure and room fit out
AI helper
Public tender to engage a qualified principal contractor for design and construction of an endoscopy procedure room upgrade at Princess Alexandra Hospital. Scope includes refurbishment, reconfiguration, remaining design development, construction, subcontractor coordination, commissioning, defects management and handover within a live operational hospital. Works include medical gases, electrical, ICT, hydraulic, mechanical/HVAC, nurse call, radiation shielding, fire services and fitout. Tender closes 30 November 2026. Supplier queries cutoff 23 November 2026. Expected decision 28 February 2027.
EOI for Callide Electorate Office Refurbishment ( Biloela, QLD) - QPS is seeking interest from qualified building companies to project manage and refurbish the Callide Electorate Office located at 64 Callide Street, Biloela Qld **** refer to the following documents for further details of this Expression of Interest ( EOI). If your company is interested in being involved in the Invitation to Tender ( ITO) phase for this refurbishment of the Callide Electorate Office, please submit a response to this
Refurbishment of the Callide electorate office Office fitout including partitions, ceilings, glazing, doors, floor coverings, paint, window coverings, workstations, loose furniture, joinery, reception counter, kitchenette, air conditioning, electrical, lighting, power outlets, hot water system, telecommunications, structured cabling, audio visual, security systems, MATV, fire services, signage, and relocation services
AI helper
QPS seeks interest from qualified building companies to project manage and refurbish the Callide electorate office at 64 Callide Street, Biloela QLD **** responses due by 16 November 2026. Successful respondents will be invited to the tender (ITO) phase. The fitout must comply with relevant legislation, Australian standards, and the National Construction Code. Scope includes partitions, ceilings, glazing, doors, finishes, workstations, joinery, air conditioning, electrical, telecommunications, security, fire services, signage, and relocation of office contents. A provisional allowance of $6,000 for advertising signage is noted.
A minimum warranty period of 5 years is required on all parts and components for workstations and loose furniture, as stated: A minimum warranty period of 5 years is required on all parts and components.
Contractors must hold relevant licenses and registrations, including: All contractors must provide and hold a class 2 license for queensland and registered contractors with an open registration for ICT cabling work.
CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
Design and construction of refurbishment works to Shop 11, meeting room, within the heritage Campbell' s Corner building Refurbishment works to Shop 11, meeting room, heritage building renovation, design and construction services
AI helper
Muswellbrook Shire Council seeks submissions for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** closes 19 November 2026. Working hours 7am-5pm Monday to Friday. Liquidated damages $100 per day. Defects liability period 12 months. Public liability insurance $20 million. Security: bank guarantees each 2. 5% of contract sum, retention 10% of each payment until 5% retained. Payment claims by 28th day of each month. Indigenous participation target applies.
The contractor must claim payment progressively, with payment claims due on the 28th day of each month. The principal pays the scheduled amount within 15 business days after receiving the payment claim. time for payment claims 28th day of each month
The contractor warrants that all material and equipment supplied will be new, fit for purpose, and comply with the National Construction Code. all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code
Liquidated damages are $100 per day if the works do not reach completion by the date for completion. liquidated damages rate 100 per day
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 30.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
