Effluent Management Tenders

submissions shall be lodged on or before the closing time of 4pm est, wednesday 4th november 2026.

the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

the respondent is responsible for and warrants that it has . . . necessary skills and expertise to be able to competently supply the scope of works.

there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

closing time of 4pm est, Wednesday 4th November 2026

12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor

there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification

closing time of 4pm est, wednesday 4th november 2026

12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor

there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification

"closing time of 4pm est, wednesday 4th november 2026"

"12 months warranty on all workmanship from the date of the practical completion inspection"

"submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor"

"necessary skills and expertise to be able to competently supply the scope of works"

"there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome"

"supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time"

"any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process"

Completion of all components of the works, including commissioning, is required by 17 December 2027. Completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. Progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

The contractor provides 12 months warranty on all workmanship from practical completion. The contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Contractors must have necessary skills, expertise, and systems to manage safety. The respondent is responsible for and warrants that it has: . . . the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. Failure to maintain progress in accordance with the approved project schedule . . . may result in the application of liquidated damages or other applicable contractual remedies.

There is no mandatory site visit, but requests are welcome. There is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

Canvassing council employees or direct contact outside the approved channel results in automatic disqualification. Any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.