Floor Coverings Tenders

Quotations must be lodged by the close date. The RFQ states: close date: 13th november 2026 @2pm.

Payment is made within 30 days of receiving a valid tax invoice. The document states: the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice.

The contractor warrants the works will be free from defects and fit for purpose. The document states: be free from any charge, liability or defect comply with all applicable standards be fit for purpose.

The award is based on best value for money. The document states: awarded to the respondent who best demonstrates the ability to provide best value for money.

Contractors must be experienced and licensed. The document states: all work must be carried out by experienced and licensed personnel in the field of work specified.

If works are not completed on time, TSIRC may remove the work order. The document states: tsirc nominated representatives have the authority to remove the system work order from the contractor.

Incomplete or amended schedules will be non-conforming. The document states: if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.

Quotations close on 13th November 2026 at 2pm. The RFQ states: close date: 13th november 2026 @2pm.

Payment is made within 30 days of receiving a valid tax invoice. The document states: the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice.

The contractor warrants the works will be free from defects, comply with standards, and be fit for purpose. The document states: be free from any charge, liability or defect comply with all applicable standards be fit for purpose.

The award is based on best value for money. The document states: the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

All work must be carried out by experienced and licensed personnel. The document states: all work must be carried out by experienced and licensed personnel in the field of work specified.

If works are not completed within the requested timeframe, the work order may be removed. The document states: tsirc nominated representatives have the authority to remove the system work order from the contractor.

Incomplete quotation forms or amended schedules will be classed as non-conforming. The document states: if the quotation form and response schedules are not completed the rfq will be classed as non- conforming.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants the works will be free from defects and fit for purpose. the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose

Best value for money, assessing price and non-price criteria. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome

All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified

RFQ non-conforming if schedules incomplete or amended. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming

A minimum warranty period of 5 years is required on all parts and components for workstations and loose furniture. A minimum warranty period of 5 years is required on all parts and components

Quotation must be lodged by 18 November 2026 at 2pm. The close date is stated as close date: 18th november 2026 @2pm.

Payment is lump sum on completion with progress claims considered upon request. Contractor paid within 30 days of receiving a valid tax invoice.

Defect liability period is 12 months from completion date. Contractor must remedy defects within 30 days of being notified by tsirc at no additional cost.

Award based on best value for money with weightings: local content spend and employment 15 tender price and commercial terms 45 quality, reliability and historical performance 15 occupational health and safety swms 10 ability to commence complete on schedule 15.

All work must be carried out by experienced and licensed personnel in the field of work specified. Contractors must hold appropriate insurances including public liability insurance of $20,000,000.

If works not completed within requested timeframe, tsirc nominated representatives have the authority to remove the system work order from the contractor and undertake work by other means.

RFQ will be classed as non-conforming if the lump sum price breakdown schedule is amended or if quotation form and response schedules are not completed.