Replacement of Evaporative Cooler Units Feeding the GSCC Stone Pavilion - The Town of Gawler is seeking quotes from suitably qualified and experienced contractors for the construction of a new, elevated structural plant platform and the replacement of the existing evaporative cooling system servicing the Stone Pavilion at the Gawler Sport and Community Centre. An informal briefing session will be held at **** on Thursday 22 October 2026 at the Gawler Sport and Community Centre. - Please see below contac
Construction of a structural plant platform and replacement of evaporative cooler units feeding the stone pavilion at the Gawler Sport and Community Centre Option A: Construction of structural plant platform and replacement of evaporative cooler units; Option B: Replacement of existing evaporative cooler units utilizing existing support structure and services
AI helper
RFQ for construction of elevated structural plant platform and replacement of two evaporative cooler units at Gawler Sport and Community Centre. Two options: Option A includes new platform and full replacement; Option B replaces units on existing structure. Quotes due 5:00 PM Adelaide time, 6 November 2026 via VendorPanel. Informal briefing on 22 October 2026. Works must be completed by 15 January 2027. Lump sum fixed pricing including GST. Requires licensed building work contractors and relevant trade licenses. Local economic benefit considered in evaluation.
Works are required to be completed by 15th January 2027. The RFQ states: works are required to be completed by 15th january 2027.
Respondents must hold a building work contractor license and relevant trade licenses. The RFQ states: individuals and companies must be licensed building work contractors as per the building classification and types of building work required in this rfq.
An informal briefing session will be held. The RFQ states: an informal briefing session is to be conducted at: **** pm adelaide time on thursday 22nd october 2026 gawler sport and community centre receptionfoyer nixon terrace, gawler south australia ****.
Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
Weir tower access walkway replacement Replacement of existing elevated walkway to access weir tower during flood inundation events, removal and demolition of existing structural steel walkway including platform and handrails, maintenance and remediation of existing steel trestles including abrasive blasting and painting
AI helper
Tenders invited for replacement of existing elevated walkway to weir tower, including demolition of existing structural steel walkway, platform and handrails, and remediation of steel trestles via abrasive blasting and painting. Contract is lump sum or schedule of rates per **** completion due 25 March 2027. Liquidated damages $500 per day. Defects liability period 12 months. Security: two unconditional bank guarantees at 5% of contract sum. Public liability insurance minimum $20,000,000. Contact Paul Weston at 07 **** **** closes 24 November 2026.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts. The contract states: payment period means: if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents and the contract requires standard risk prequalified suppliers for the weir tower access walkway replacement project.
Liquidated damages are set at $500 per day for delay, as stated in the annexure: liquidated damages, rate subclause 34. 7 500 per day.
Replacement of Evaporative Cooler Units Feeding the GSCC Stone Pavilion - The Town of Gawler is seeking quotes from suitably qualified and experienced contractors for the construction of a new, elevated structural plant platform and the replacement of the existing evaporative cooling system servicing the Stone Pavilion at the Gawler Sport and Community Centre. An informal briefing session will be held at **** on Thursday 22 October 2026 at the Gawler Sport and Community Centre. - Please see below contac
Construction of a structural plant platform and replacement of evaporative cooler units feeding the stone pavilion at the Gawler Sport and Community Centre Option A: Construction of structural plant platform and replacement of evaporative cooler units; Option B: Replacement of existing evaporative cooler units utilizing existing support structure and services
AI helper
Request for Quote for construction of a new elevated structural plant platform and replacement of two evaporative cooler units at the Gawler Sport and Community Centre. Two options: Option A includes platform construction and unit replacement; Option B only unit replacement using existing structure. Quotes due 5:00 PM Adelaide time, 6 November 2026 via VendorPanel. Informal briefing on 22 October 2026. Works must be completed by 15 January 2027. Lump sum fixed pricing required. Building work contractor license and relevant trade licenses required. Local economic benefit considered in evaluation.
Works are required to be completed by 15th January 2027. The RFQ states: works are required to be completed by 15th january 2027.
Respondents must hold a building work contractor license and relevant trade licenses. The RFQ states: individuals and companies must be licensed building work contractors as per the building classification and types of building work required in this rfq.
An informal briefing session is scheduled. The RFQ states: an informal briefing session will be held at **** on thursday 22 october 2026 at the gawler sport and community centre.
Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.
Replacement of Evaporative Cooler Units Feeding the GSCC Stone Pavilion - The Town of Gawler is seeking quotes from suitably qualified and experienced contractors for the construction of a new, elevated structural plant platform and the replacement of the existing evaporative cooling system servicing the Stone Pavilion at the Gawler Sport and Community Centre. An informal briefing session will be held at **** on Thursday 22 October 2026 at the Gawler Sport and Community Centre. - Please see below contac
Construction of a structural plant platform and replacement of evaporative cooler units feeding the stone pavilion at the Gawler Sport and Community Centre Option A: Construction of structural plant platform and replacement of evaporative cooler units; Option B: Replacement of existing evaporative cooler units utilizing existing support structure and services
AI helper
Quotes sought for construction of elevated structural plant platform and replacement of evaporative cooler units at Gawler Sport and Community Centre. Two options: Option A includes new platform and full replacement; Option B replaces units on existing structure. Informal briefing on 22 October 2026. Quotes due 6 November 2026 via VendorPanel. Works must be completed by 15 January 2027. Fixed lump sum pricing including GST. Building work contractor license required. Local economic benefit considered.
Works are required to be completed by 15th January 2027. The RFQ states: works are required to be completed by 15th january 2027.
Licensed building work contractors are required. The RFQ states: individuals and companies must be licensed building work contractors as per the building classification and types of building work required in this rfq.
An informal briefing session is available. The RFQ states: an informal briefing session will be held at **** on thursday 22 october 2026 at the gawler sport and community centre.
Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.
Replacement of Evaporative Cooler Units Feeding the GSCC Stone Pavilion - The Town of Gawler is seeking quotes from suitably qualified and experienced contractors for the construction of a new, elevated structural plant platform and the replacement of the existing evaporative cooling system servicing the Stone Pavilion at the Gawler Sport and Community Centre. An informal briefing session will be held at **** on Thursday 22 October 2026 at the Gawler Sport and Community Centre. - Please see below contac
Construction of a structural plant platform and replacement of evaporative cooler units feeding the stone pavilion at the Gawler Sport and Community Centre Option A: Construction of structural plant platform and replacement of evaporative cooler units; Option B: Replacement of existing evaporative cooler units utilizing existing support structure and services
AI helper
RFQ for construction of a new elevated structural plant platform and replacement of two evaporative cooler units at Gawler Sport and Community Centre. Two options: Option A includes platform construction and unit replacement; Option B only unit replacement using existing structure. Quotes due 5:00 PM Adelaide time, 6 November 2026 via VendorPanel. Informal briefing on 22 October 2026. Works must be completed by 15 January 2027. Lump sum fixed pricing including GST. Requires licensed building work contractors and relevant trade licenses. Local economic benefit considered in evaluation.
Works are required to be completed by 15th January 2027. The RFQ states: works are required to be completed by 15th january 2027.
Respondents must hold a building work contractor license and relevant trade licenses. The RFQ states: individuals and companies must be licensed building work contractors as per the building classification and types of building work required in this rfq.
An informal briefing session is scheduled. The RFQ states: an informal briefing session will be held at **** on thursday 22 october 2026 at the gawler sport and community centre.
Quotes received after the closing date will not be considered. The RFQ states: quotes received after the closing date will not be considered.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Plans start at A$ 30.00/month, with options for different needs and subscription terms. Plans are prepaid: check the total amount and duration before confirming. Start with the free trial and assess the results before subscribing, with no automatic charges.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
