Goondiwindi Regional Council seeks tenders for the civil and mechanical works package of the Texas WWTP upgrade. Work includes construction, installation, testing, commissioning support and closeout. Lump sum contract under AS 4000:2025. Completion required by 17 December 2027. Tenders due 4:00 PM EST, 4 November 2026 (website lists 20 November 2026). No mandatory site visit, but requests welcome. Prices inclusive of GST. Retention of 10% per progress payment. 12-month warranty on workmanship. Public liability insurance of $20 million required. Submissions via Vendor Panel.
Completion of all components of the works, including commissioning, is required by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.
Progress claims may be submitted for works fully executed on site, including labour, plant, and installation, or for materials delivered to site. progress claims may be submitted for works fully executed on site
The contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection. the contractor is responsible to provide 12 months warranty on all workmanship
Contractors must have necessary skills and expertise, and complete the Contractor WHS Questionnaire. the respondent is responsible for and warrants that it has: . . . the necessary skills and expertise to be able to competently supply the scope of works.
Failure to maintain progress may result in liquidated damages. failure to maintain progress in accordance with the approved project schedule . . . may result in the application of liquidated damages
There is no mandatory site visit, but requests are welcome via the Vendor Panel question portal. there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.
Any form of canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification