Twentieth Street Stormwater Upgrade - The Town of Gawler is seeking a suitably qualified and experienced Civil Contractor to undertake works to upgrade the existing stormwater infrastructure in Twentieth Street by installing new pits, culverts, junctions and connection to the existing Council stormwater network at Adelaide Road.
Stormwater infrastructure upgrade works in Twentieth Street, Gawler South Installation of new stormwater pits, culverts, junctions, connection to existing council stormwater network at Adelaide Road, kerb and gutter renewal, road pavement and reinstatement, trenching, backfill and compaction, demolition and disposal of existing materials, traffic and pedestrian management, as- constructed survey and CCTV inspection
AI helper
Town of Gawler seeks a qualified civil contractor for stormwater upgrade in Twentieth Street, Gawler South. Works include new pits, culverts, junctions, connection to existing network, kerb renewal, and reinstatement. Tenders due 13 November 2026, 5pm Adelaide time via VendorPanel. Contact Alec Walsh. Evaluation uses weighted criteria including price, experience, methodology, and local economic benefit. Defect liability period of 12 months. Site constraints include tree protection zones and third-party service relocations.
The evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be considered in the selection of a preferred tenderer.
Tenders lodged by any other means will not be considered. Tenders received after the closing date will not be considered or accepted.
Twentieth Street Stormwater Upgrade - The Town of Gawler is seeking a suitably qualified and experienced Civil Contractor to undertake works to upgrade the existing stormwater infrastructure in Twentieth Street by installing new pits, culverts, junctions and connection to the existing Council stormwater network at Adelaide Road.
Stormwater infrastructure upgrade works in Twentieth Street, Gawler South Installation of new stormwater pits, culverts, junctions, connection to existing council stormwater network at Adelaide Road, kerb renewal, road pavement and reinstatement, trenching, backfill and compaction, demolition and disposal of existing materials, traffic and pedestrian management, as- constructed survey and CCTV inspection
AI helper
Town of Gawler seeks a qualified civil contractor for stormwater infrastructure upgrade in Twentieth Street, Gawler South. Works include new pits, culverts, junctions, connection to existing network, kerb renewal, and road reinstatement. Tenders must be lodged electronically via VendorPanel by 5pm Adelaide time, 13 November 2026. Contact: Alec Walsh, Project Manager Capital Works. A 12-month defect liability period applies. Tenderers must complete all response schedules and comply with WHS, environmental, and traffic management requirements.
Tenders must be lodged electronically via VendorPanel before the closing date, 5pm Adelaide time on 13 November 2026. tenders must be lodged electronically via vendorpanel before the closing date 5pm adelaide time on 13 november 2026.
The works include a defect liability period of 12 months from the date of practical completion. defect liability period for 12 months from the date of practical completion.
Tenderers must be licensed or registered to perform the works and provide details of relevant licenses and accreditations. each tenderer must if applicable be licensed or registered to perform the works.
Tenders received after the closing date will not be considered or accepted. tenders received after the closing date will not be considered or accepted.
Council Facilities Minor Works, Asset Maintenance and Associated Services Standing Offer Agreement - Scenic Rim Regional Council is situated in South- East Queensland, recognised for its stunning landscapes and vibrant communities. The Council is dedicated to enhancing the quality of life for residents and visitors through sustainable development and economic growth, partnering with reputable contractors to support ongoing projects. The Scenic Rim Regional Council is inviting tenders for the supply of minor
Council facilities minor works, asset maintenance and associated services standing offer arrangement Minor works, asset maintenance, building maintenance, cleaning services, electrical services, lighting, furniture, mechanical plant, air conditioning maintenance, lift maintenance, refrigeration, playground inspection and maintenance, plumbing, roofing, tiling, waterproofing, window coverings, graffiti removal, gutter cleaning, outdoor and park furniture
AI helper
Scenic Rim Regional Council invites tenders for minor works, asset maintenance and associated services for council facilities across the Scenic Rim region, Queensland. Initial contract term is 2 years from 1 November 2026 to 31 October 2028, with two optional 12-month extensions. Submissions due 23 October 2026 via VendorPanel portal. Evaluation based on compliance, price, value for money, and response to selection criteria including experience, safety, environmental management, and pricing. No briefing session or site inspection. Contact Jeff Baguley for technical enquiries via VendorPanel.
Submissions must be lodged electronically via the VendorPanel tendering portal by Friday, 9 October 2026 14:00 AEST. The portal closing date is 23 October 2026. submission deadline friday, 9 october 2026 14:00 aest
Submissions will be assessed based on price and overall value for money and response to selection criteria including understanding of project requirements, relevant experience, risk assessment, safety record, and pricing.
Respondents must meet all mandatory requirements including compliance with safety and regulatory standards and demonstrate relevant experience, qualifications, capacity and capability.
Site inspection is not applicable. site inspection not applicable
Requests for clarification must be submitted three days prior to the submission deadline. deadline for cutoff requests for clarification or further information are three 3 days clarification prior to the submission deadline
Respondents must meet all mandatory requirements outlined in the RFT documents, including compliance with safety and regulatory standards. respondents either meet the standard or they do not
Wilcannia Post Office Roof Repair Upgrade - The Central Darling Shire Council ( the Principal) is seeking submissions from suitably qualified, experienced, and well- resourced building contractors to provide a quote for works associated with roof upgrade of Post office in Wilcannia. Central Darling Shire Council ( the Principal) proposes to undertake essential roof repair, and remediation works at the Wilcannia Post Office in Wilcannia, NSW. The proposed works are intended to address deterioration of the ex
Roof repair and upgrade works at the Wilcannia Post Office Removal of existing damaged roof sheeting and associated materials, preparation of roof structure, installation of replacement roof sheeting and flashings, reinstatement of roof- mounted items, remediation of chimney flashings, repair or replacement of gutters and downpipes, replacement or repair of ridge capping, inspection and remediation of roof components and penetrations
AI helper
Central Darling Shire Council seeks quotes from qualified building contractors for roof repair and upgrade at Wilcannia Post Office, 49 Reid St, Wilcannia NSW. Works include replacing damaged roof sheeting, flashings, gutters, downpipes, and ridge capping, plus chimney weatherproofing. Submissions due 9 October 2026 at 5pm electronically to ***@***. *. * criteria: methodology (10), past performance (20), personnel experience (20), resources (10), price (40). Insurance required: professional indemnity $2M, public liability $20M. Completion by 30 November 2026. Heritage building, retain and repair existing fabric where practicable.
Works must be completed by 30 November 2026. The document states: completion of construction 30 november 2026.
Evaluation criteria include methodology (10), past performance (20), experience and qualifications of personnel (20), resources suitability (10), and price (40). The document states: qualitative criteria 1. methodology 10 1. past performance completing similar projects 20 1. experience and qualifications of personnel 20 1. resources suitability and capability 10 quantitative criteria 1. price 40 total 100.
Contractors must be suitably qualified, experienced, and well-resourced building contractors. The document states: seeking submissions from suitably qualified, experienced, and well- resourced building contractors.
Failure to comply with government information requirements may result in termination. The document states: any failure by the contractor to comply with any request pursuant to sub clause 1 or 3 will be considered a breach of an essential term and will allow the agency to terminate the contract.
The total proposed budget is approximately $100,000. The document states: the total proposed budget for the project is approximately 100, 000 for the wilcannia post office.
Council Facilities Minor Works, Asset Maintenance and Associated Services Standing Offer Agreement - Scenic Rim Regional Council is situated in South- East Queensland, recognised for its stunning landscapes and vibrant communities. The Council is dedicated to enhancing the quality of life for residents and visitors through sustainable development and economic growth, partnering with reputable contractors to support ongoing projects. The Scenic Rim Regional Council is inviting tenders for the supply of minor
Council facilities minor works, asset maintenance and associated services standing offer arrangement Minor works, asset maintenance, building maintenance services, cleaning services, electrical services, lighting, plumbing, roofing, tiling, waterproofing, window coverings, graffiti removal, gutter cleaning, air conditioning maintenance, lift maintenance, refrigeration, playground inspection and maintenance, outdoor and park furniture
AI helper
Scenic Rim Regional Council invites tenders for minor works, asset maintenance and associated services for council facilities across the Scenic Rim region. Initial contract term is 2 years from 1 November 2026 to 31 October 2028, with two optional 12-month extensions. Submissions due 9 October 2026 at 14:00 AEST via VendorPanel. Evaluation based on compliance, price, value for money, and weighted criteria including experience, safety, and environmental practices. No briefing session or site inspection. Clarification cutoff is 3 days before submission deadline.
Submissions must be lodged by Friday, 9 October 2026 at 14:00 AEST. The closing date is stated as 9 october 2026 in the RFT particulars.
The evaluation considers price and overall value for money along with compliance and response to selection criteria, as stated in the RFT particulars.
Respondents must meet all mandatory requirements outlined in the rft documents, including compliance with safety and regulatory standards as stated in the evaluation criteria.
Site inspection is not applicable, as stated in the RFT particulars: site inspection not applicable.
Requests for clarification must be submitted three 3 days clarification prior to the submission deadline as stated in the RFT particulars.
Failure to meet mandatory compliance criteria may result in non-compliance, as these are not weighted and scored. respondents either meet the standard or they do not.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
Good information. All the information is very good!
J. A. Tellez
It gives me information on tenders that interest me. It's easy to find tenders.
A. Armenta
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
It encompasses all portals in one place.
G. Ferrea
The tenders appear appropriately based on my interests.
V. Niembro
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 32.50 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1107 active users, conducted through 21/10/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
