C26- 152 - Footbridge Replacement - Romsey Road, Woodend - Macedon Ranges Shire Council is seeking quotation from suitably qualified contractor to demolish the existing footbridge and then design and construct a new Footbridge at the same location and carry out all related construction activities.
Design and construct a new footbridge over Five Mile Creek, Woodend, replacing the existing structure. Tender opens 21 Sep 2026, closes 20 Oct 2026. Site visit mandatory before quoting. Samples of materials required. Practical completion six months after award (09 Nov 2026). Warranty 52 weeks post?completion. No award criteria or penalties specified.
practical completion: six months from the date of contract award.
performance guarantee . . . 52 weeks from the date of practical completion.
visiting site visit the site of the proposed works before quoting to ascertain the actual extent of the work to be done.
the contractor may be directed to provide material samples.
Newstead Levee Design 26/27 - Mount Alexander Shire Council ( Council) is seeking suitably qualified and experienced floodplain, civil and structural engineering consultants to complete the detailed design, approval support, documentation and construction tender package for the Newstead Levee Design project.
floodplain, civil and structural engineering consulting services for newstead levee design detailed design, approval support, documentation and construction tender package for newstead levee design
AI helper
Mount Alexander Shire Council invites qualified floodplain, civil and structural engineering consultants to submit a quotation for detailed design, approval support, documentation and construction tender package for the Newstead Levee Design project. The quotation deadline is 2:00pm, Friday 23 October 2026. Evaluation will consider lowest price and highest stage one score, with a single delivery location. Site visits are recommended but not mandatory.
The quotation closing date is 2:00pm, Friday 23 October 2026. quotation closing date . . . 2:00pm, Friday 23 October 2026
The aim is to have a lower price and a higher stage one score, meaning the lowest result is the best value for money. the aim is to have a lower price and a higher stage one score, meaning the lowest result is the best value for money.
Consultants must be suitably qualified and experienced floodplain, civil and structural engineering consultants. suitably qualified and experienced floodplain, civil and structural engineering consultants
Consultants to visit site it is recommended that consultants visit the relevant sites. consultants to visit site it is recommended that consultants visit the relevant sites
C26- 152 - Footbridge Replacement - Romsey Road, Woodend - Macedon Ranges Shire Council is seeking quotation from suitably qualified contractor to demolish the existing footbridge and then design and construct a new Footbridge at the same location and carry out all related construction activities.
footbridge replacement Demolition of existing footbridge, design and construction of new footbridge, boardwalks, shared path connections, temporary works, site protection, traffic management, environmental compliance, and related construction activities.
AI helper
This public tender seeks a qualified contractor to demolish the existing footbridge at Romsey Road, Woodend, and design and construct a new footbridge with boardwalks and shared path connections. Site visit is mandatory before quoting, and sample submission is required. Deadline for supplier queries is 15 Oct 2026. The project is a single delivery location, with a 52?week warranty after practical completion. The council is a municipal agency.
supplier query cutoff Thursday 15 October 2026 12:00 am
performance guarantee . . . 52 weeks from the date of practical completion
visiting site visit the site of the proposed works before quoting
C26- 152 - Footbridge Replacement - Romsey Road, Woodend - Macedon Ranges Shire Council is seeking quotation from suitably qualified contractor to demolish the existing footbridge and then design and construct a new Footbridge at the same location and carry out all related construction activities.
Design and construct replacement footbridge over Five Mile Creek on Romsey Road, Woodend, including demolition of existing footbridge and related construction activities. Demolition of existing footbridge, design and construction of new footbridge, boardwalks, connecting shared paths, associated works, removal of existing bridge and materials, protection of retained vegetation, reinstatement of disturbed areas.
AI helper
Macedon Ranges Shire Council seeks a suitably qualified contractor for design and construct of a footbridge replacement over Five Mile Creek, Woodend. Includes demolition of existing bridge, design and construction of new footbridge, boardwalks, and shared paths. Minimum 100-year design life. Lump sum fixed price contract. Site visit required before quoting. Practical completion six months from contract award. Defects liability period 52 weeks. Tender closes 20 October 2026.
Practical completion is required within six months from the date of contract award. The project timeline states: practical completion: six months from the date of contract award.
Progress claims are submitted to the superintendent with details of work completed, variations, and deductions. The contract states: number each progress claim consecutively and submit to the superintendent a schedule giving the following particulars.
The contractor must guarantee performance for 52 weeks from practical completion. The specification states: the contractor shall guarantee the performance of the works under normal working conditions for a period of fifty two 52 weeks from the date of practical completion.
Tenderers must be suitably qualified contractors. The request states: seeking quotation from suitably qualified contractor to demolish the existing footbridge and then design and construct a new footbridge.
A site visit is required before quoting. The specification states: visit the site of the proposed works before quoting to ascertain the actual extent of the work to be done.
Vertical Transport Asset Replacement Program Stage 1 - Design & Construction - - Background The Vertical Transport Replacement Program & ndash; Stage 1 involves the replacement of the lifts and escalators identified in Table 1 at Kwinana, Bassendean, Clarkson and Perth Underground stations. These assets have reached, or are approaching, the end of their service life. An approved Project Definition Plan has confirmed the operational need for their replacement. The following factors substantiate the requireme
Vertical transport asset replacement program stage 1 - design & construction Replacement of lifts and escalators at Kwinana, Bassendean, Clarkson and Perth Underground stations, including detailed design, IFC documentation, as- constructed drawings, associated structural, electrical, communications, mechanical, fire and system interface works, removal and disposal of existing assets
AI helper
Design and construct contract for replacement of lifts and escalators at four Perth stations. Mandatory briefing on 27 Oct 2026 at 116 West Parade, Perth; attendance required for bid eligibility. Registration by 26 Oct 2026. Responses close 26 Nov 2026 11:00 AM Perth time. Scope includes detailed design, IFC documentation, construction, and as-constructed drawings. Aboriginal participation requirements apply.
Responses close on Thursday, 26 November 2026 at 11:00 AM Perth time. responses closes thu, 26 nov 2026 at 11: 00am perth, western australia
Attendance at the mandatory briefing is required for eligibility. any respondents who fail to attend or be represented at the mandatory briefing shall not be eligible for consideration under this request
A site visit will be held at 116 West Parade, Perth on 27 October 2026 at 2:00 PM. a site visit will be held at 116 west parade, perth on 27 oct, 2026 2: 00 pm
Failure to attend the mandatory briefing disqualifies the respondent. any respondents who fail to attend or be represented at the mandatory briefing shall not be eligible for consideration under this request
We selected helpful reviews from real users. Order may change periodically.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
Good information. All the information is very good!
J. A. Tellez
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
The platform is very user-friendly.
N. Lobato
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
A very good platform.
D. C. Espinosa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
M. F. Cortez
Excellent information. Just what I was looking for.
L. H. Borrelli
They notify me promptly when a contest is published.
L. Salazar
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 32.50 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1107 active users, conducted through 21/10/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
