Darwin Region - Rural Roads - Bituminous Pavement Repairs for a Period of 36 Months - Bituminous repairs and minor rehabilitation of existing sealed roads and highways including but not limited to: - Pothole Patching - Edge Break Repairs - Regulation Patching - Reconstruction Patching - Spray Sealing - Minor reconstruction with surface works The contractor will be required to undertake pothole inspections on a number of higher use important roads - fortnightly in November and from April to May, and weekly
Bituminous pavement repairs and minor rehabilitation of existing sealed roads and highways Pothole patching, edge break repairs, regulation patching, reconstruction patching, spray sealing, minor reconstruction with surface works
AI helper
Contract covers bituminous repairs and minor rehabilitation of rural roads in the Darwin region for 36 months. Works include pothole patching, edge break repairs, and spray sealing. The contractor must use the Konect electronic management system for inspections and defect logging. Tender closing date is 22 September 2026. Indigenous Development Plan submission is required within 14 days of contract award.
Payment for scheduled work will be made at the tendered rate. payment for scheduled work will be made at the tendered rate.
The contractor must provide warranties for workmanship and manufacturers and/or suppliers warranties for products used in the works, in the name of the principal. provide warranties for workmanship and manufacturers and/or suppliers warranties for products used in the works, in the name of the principal.
Tender responses will be shortlisted based on: completeness of response, local content, past performance, whether the tender response presents an acceptable level of risk to the principal and price. tender responses will be shortlisted based on: completeness of response, local content, past performance whether the tender response presents an acceptable level of risk to the principal and price.
A fully developed Indigenous Development Plan will be required within fourteen 14 days of contract award. a fully developed plan will be required within fourteen 14 days of contract award.
Failure to meet service levels can result in adverse contractor performance scorecard notation, disputed invoices, or breach of contract notice. relevant invoices will be disputed if relevant, breach of contract notice may be issued to contractor for failure to meet overall contracted standard of delivery of works.
Tully Civic Centre External Building Remediation, Repainting and Signage Works - Cassowary Coast Regional Council is seeking quotations from suitably qualified contractors for the **** - Tully Civic Centre External Building Remediation, Repainting and Signage Works located at 34- 40 Bryant Street, Tully QLD 4854. The Works generally include external building remediation and repainting works, scaffolding and access requirements, removal and installation of signage, cleaning and preparation of external surf
External building remediation, repainting and signage works External building remediation, repainting, scaffolding, access requirements, signage removal and installation, cleaning and preparation of external surfaces.
AI helper
Cassowary Coast Regional Council seeks quotations for external building remediation, repainting, and signage works at Tully Civic Centre. The works include remediation, repainting, scaffolding, signage removal/installation, and surface preparation. A mandatory site inspection is held on 23/09/2026. Quotations must be submitted via VendorPanel by 01/10/2026 17:00 AEST. Evaluation criteria include price (30%), program (25%), methodology (25%), experience (10%), and local content (10%). The works must be completed by 31/05/2027. If Dulux paint is used, notification to Dulux is required at least 7 days prior to commencement.
The works must be completed by 31 May 2027.
Respondents must provide all required warranties, manuals, product information and handover documentation for practical completion.
Evaluation criteria weighting price 30 program 25 methodology 25 experience 10 local content 10.
Respondents are required to submit a proposed program for the works.
A site inspection is held at **** Bryant Street Tully on Wednesday 23rd September 2026 at 10:00am.
2027/334 Footpath Program - Merbein - Reilly Street, River Avenue and Commercial Street - Mildura Rural City Council is seeking Tender responses from suitably qualified contractors to undertake civil construction works associated with the Footpath Program - Merbein - Reilly Street, River Avenue and Commercial Street project. This will include demolition and site preparation works, construction of reinforced concrete footpaths, construction of new pram ramps completes with Tactile Ground Surface Indicators
Civil construction works for footpath program Demolition and site preparation works, construction of reinforced concrete footpaths, construction of new pram ramps complete with tactile ground surface indicators, localised earthworks, adjustment of existing infrastructure, landscaping and reinstatement works, and post- project site cleanup.
AI helper
Mildura Rural City Council seeks tenders for civil construction works for the footpath program in Merbein (Reilly Street, River Avenue, and Commercial Street). Works include demolition, site preparation, concrete footpath construction, and pram ramp installation. Submissions must be electronic via vendorpanel by September 17, 2026, 01:00 am E. South America Standard Time. Site inspection is available on request but not mandatory. Council reserves the right to select respondents as it sees fit.
A site inspection with council is available on request via the forum. inspections are recommended however not mandatory.
Rosny and Richmond Tennis Courts - Resurface - Council invites Tenders to undertake works as specified in these Tender Documents for the following works at the Rosny and Richmond Tennis Courts sites. Rosny Tennis Club, Courts 1& 2 - 18 Bastick Street, Rosny - Supply of all materials and consumables for the resurfacing of courts 1 and 2 - Supply of portable toilet and amenities for the duration of the works - Install new sand filled synthetic grass surface - Removal and appropriate disposal of all waste mate
Tennis court resurfacing and installation of synthetic grass surface Rosny Tennis Club, Courts 1& 2: Supply of materials/consumables for resurfacing, portable toilet/amenities, installation of new sand filled synthetic grass, waste removal. Richmond Tennis Club, Courts 1& 2: Supply of materials/consumables for guttering/resurfacing, portable toilet/amenities, removal of existing synthetic grass, installation of new sand filled synthetic grass, waste removal.
AI helper
Council invites tenders for resurfacing works at Rosny and Richmond tennis courts. Works include supplying materials, installing new sand filled synthetic grass, and waste disposal. A pretender site meeting is scheduled for Thursday, September 17th, 2026. The close of tender is Tuesday, October 6th, 2026, at 3pm. All site works must be completed prior to December 31, 2026.
All site works must be completed prior to 31 dec 2026.
A pretender site meeting is scheduled for rosny tennis club 18 bastick street at 11: 30am on thursday 17 september onsite.
Tully Civic Centre External Building Remediation, Repainting and Signage Works - Cassowary Coast Regional Council is seeking quotations from suitably qualified contractors for the **** - Tully Civic Centre External Building Remediation, Repainting and Signage Works located at 34- 40 Bryant Street, Tully QLD 4854. The Works generally include external building remediation and repainting works, scaffolding and access requirements, removal and installation of signage, cleaning and preparation of external surf
External building remediation, repainting and signage works External building remediation, repainting, scaffolding, access requirements, signage removal and installation, cleaning and preparation of external surfaces.
AI helper
Cassowary Coast Regional Council seeks quotations for external building remediation, repainting, and signage works at Tully Civic Centre. The works include scaffolding, cleaning, and surface preparation. Quotations must be submitted via VendorPanel by 1 October 17:00 AEST. Evaluation criteria include price (30%), program (25%), methodology (25%), experience (10%), and local content (10%). A mandatory site inspection is held on Wednesday, 23rd September 2026 at 10:00 am. The works must be completed by 31 May 2027.
The works must be completed by 31 May 2027.
If dulux paint is used, the contractor must notify casey ngatai from dulux on **** 989 or email ***@***. *. * at least 7 days before commencing this project. to ensure support any warranties via proof of purchase.
Evaluation criteria weighting price 30 program 25 methodology 25 experience 10 local content 10.
Respondents are required to submit a proposed program for the works.
A site inspection is held at **** Bryant Street Tully on Wednesday 23rd September 2026 at 10:00am. site inspection held at **** bryant street tully on wednesday 23rd september 2026 at 10:00am
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Excellent information. Just what I was looking for.
L. H. Borrelli
Fast, flexible, and simple.
E. Disruptivas
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They notify me promptly when a contest is published.
L. Salazar
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I am very satisfied; it's a very useful tool.
J. S. Garcia
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I quickly find the tenders that interest me.
S. Roque
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
