The tender is for the construction, testing, and commissioning of Maturation Pond 1 at the Texas wastewater treatment plant, Goondiwindi, Queensland. It is a lump?sum contract with a submission deadline of **** and a completion deadline of **** will consider price, past performance, technical expertise, WHS systems, availability, and local contractor status. Site visits are optional. A 12?month workmanship warranty applies.
The works must be completed by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.
Progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use. progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.
Contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection. contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.
Submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor WHS systems, availability, and local contractor. submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
Contractor must have the necessary skills and expertise to supply the scope of works. the necessary skills and expertise to be able to competently supply the scope of works.
A portion of each progress payment, equivalent to 10% of the value of work completed exclusive of GST, shall be retained by council as retention money. a portion of each progress payment, equivalent to 10 of the value of work completed exclusive of gst, shall be retained by council as retention money.
There is no mandatory site visit for these works but requests for a site visit during the tender period are welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
Supplier query cutoff is Wednesday 04 November 2026 03:00 am. supplier query cutoff wednesday 04 november 2026 03:00 am e. south america standard time.
Any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.
