Structural Steel Demolition/ Steel Structure Remediation/ Structural Steel Works
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
Weir tower access walkway replacement Replacement of existing elevated walkway to access weir tower during flood inundation events, removal and demolition of existing structural steel walkway including platform and handrails, maintenance and remediation of existing steel trestles including abrasive blasting and painting
AI helper
Tenders invited for replacement of existing elevated walkway to weir tower, including demolition of existing structural steel walkway, platform and handrails, and remediation of steel trestles via abrasive blasting and painting. Contract is lump sum or schedule of rates per **** completion due 25 March 2027. Liquidated damages $500 per day. Defects liability period 12 months. Security: two unconditional bank guarantees at 5% of contract sum. Public liability insurance minimum $20,000,000. Contact Paul Weston at 07 **** **** closes 24 November 2026.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts. The contract states: payment period means: if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents and the contract requires standard risk prequalified suppliers for the weir tower access walkway replacement project.
Liquidated damages are set at $500 per day for delay, as stated in the annexure: liquidated damages, rate subclause 34. 7 500 per day.
TCW00743/TCW00751 - RFO/SOA - Reservoir Renewal Program - Please refer to TCW00743/TCW00751 - Request for Offer documentation.
Standing offer arrangement for reservoir renewal program construction services Reservoir roof replacement and renewal works, structural steel remediation, concrete repair, protective coating removal and recoating, cathodic protection installation, mechanical and pipework rehabilitation, electrical instrumentation and control upgrades, safety access improvements, reservoir cleaning and disinfection, civil works, site establishment, temporary works, traffic management, environmental controls
AI helper
Council seeks to establish a standing offer arrangement with up to three contractors for reservoir renewal works over four years, with two optional extension periods of two years each. Initial projects include Yarrawonga, Rollingstone, and Bottom City reservoir renewals. Evaluation uses a three-stage value for money assessment with threshold criteria and weighted criteria including local industry participation, capability, methodology, resources, and safety. Offers must be submitted electronically before the closing date. Suppliers must hold required licences, insurances, and demonstrate financial capacity and relevant experience.
The evaluation uses a three-stage value for money assessment comprising threshold criteria, weighted evaluation criteria, and value for money assessment. Weighted criteria include local industry participation (10%), social benefit (5%), capability (25%), methodology (30%), resources (20%), and safety (10%).
Threshold criteria include submission of all documents, financial capacity evidence, required licences, relevant experience, management systems, insurances, and supplier code of conduct compliance.
Any offer that contains qualifications will be deemed to be an alternative offer. Failure to comply with all requirements may result in an offer being considered an alternative offer, which may not be evaluated.
**** - Weir Tower Access Walkway Replacement - Charters Towers Regional Council invites tenders from suitably qualified respondents to complete the works required for the Weir Tower Access Walkway Replacement Project. This project, Weir Tower Access Walkway Replacement, includes the replacement of the existing elevated walkway to access the Weir Tower during flood inundation events. The project will include the removal and demolition of the existing structural steel walkway including the platform and ha
Weir tower access walkway replacement Replacement of existing elevated walkway to access weir tower during flood inundation events, removal and demolition of existing structural steel walkway including platform and handrails, maintenance and remediation of existing steel trestles including abrasive blasting and painting
AI helper
Charters Towers Regional Council invites tenders for replacement of existing elevated walkway to access weir tower during flood events. Works include demolition of existing structural steel walkway, platform and handrails, and remediation of existing steel trestles via abrasive blasting and painting. Contract is construct only, lump sum, with practical completion by 25 March 2027. Tender closes 24 November 2026. Contact Paul Weston at 07 **** ****.
Practical completion is due by 25th March 2027, as stated: date for practical completion clause 1 25th march 2027.
Progress claims are due on the 21st day of each month, with payment period of 15 business days for building contracts, as stated: payment period means: 1. if the contract is a building contract, 15 business days.
Tenders are invited from suitably qualified respondents to complete the works, as stated: invites tenders from suitably qualified respondents to complete the works required.
Liquidated damages are set at $500 per day, as stated: liquidated damages, rate subclause 34. 7 500 per day.
Supplier query cutoff is Thursday 19 November 2026, as stated: supplier query cutoff thursday 19 november 2026 04: 00 am.
Contractor must not engage in improper conduct, including collusive tendering or anticompetitive conduct, as stated: engaging in any collusive tendering, anticompetitive conduct, or any other unlawful or unethical conduct.
TCW00743/TCW00751 - RFO/SOA - Reservoir Renewal Program - Please refer to TCW00743/TCW00751 - Request for Offer documentation.
Standing offer arrangement for reservoir renewal program construction services Reservoir roof replacement and renewal works, structural steel remediation, concrete repair, protective coating removal and recoating, cathodic protection installation, mechanical and pipework rehabilitation, electrical instrumentation and control upgrades, safety access improvements, reservoir cleaning testing disinfection commissioning, civil works, site establishment, temporary works, traffic management, environmental controls
AI helper
Standing offer arrangement for reservoir renewal program in Townsville. Initial projects include Yarrawonga, Rollingstone, and Bottom City reservoir renewals. Up to three contractors may be appointed. SOA term is 4 years with two 2-year extension options. Evaluation uses three-stage value for money assessment with threshold criteria and weighted criteria including local industry participation, social benefit, capability, methodology, resources, and safety. Offers must be submitted electronically before closing date. Concurrent RFO participation required for at least one project.
The evaluation uses a three-stage value for money assessment comprising threshold criteria, weighted evaluation criteria, and value for money assessment. Weighted criteria include local industry participation (10%), social benefit (5%), capability (25%), methodology (30%), resources (20%), and safety (10%).
Threshold criteria include submission of all documents, concurrent RFO participation, financial capacity evidence, required licences, relevant experience, management systems, insurances, and supplier code of conduct compliance.
Offers containing qualifications will be deemed alternative offers. Failure to address any evaluation criterion may result in the offer being deemed alternative. Offers not delivered before closing date may be rejected.
Fatigue Treatments to Steel Sections of the West Gate Bridge - Critical Location 18 - **** - Fatigue Treatments to Steel Sections of the West Gate Bridge - Critical Location 18 Tender Opening Date: 30 September 2026 Tender Closing Date: 4 November 2026 Tender documents can be obtained via email after the relevant confidentiality deed has been submitted to the nominated contact below ( download deed from attachments). Contact: Ilyas Rezai, email [ email protected] PREQUALIFICATION Only Tenderers prequali
Fatigue treatments to steel sections of the West Gate Bridge - Critical Location 18 Fatigue treatments to steel sections of the West Gate Bridge, Critical Location 18
AI helper
Tender for fatigue treatments to steel sections of the West Gate Bridge, Critical Location 18. Tender closing date: 4 November 2026 at 5:00pm via tenders. vic. gov. au. Prequalification at minimum levels B3 and F2 required. Pre-tender briefing on 13 October 2026 at 10:00am at 10 Sardine Street, Port Melbourne. Site inspection highly recommended but not mandatory. Documents available via email after submitting confidentiality deed.
Prequalification is required: prequalification only tenderers prequalified at minimum prequalification levels b3 f2 at the time of closing of tenders will be eligible to tender on this contract.
A site inspection is optional but recommended: a site inspection is not mandatory, but it is highly recommended, with attendance forming part of the tender evaluation.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
