Building Renovation/ Interior Fitout/ Kitchen Renovation/ Bathroom Renovation/ Laundry Renovation
****- ****- Lot 39 Bani Street, Mabuiag ( Int Works/Painting/Kitchen/Bahroom/Laundry) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refe
Internal works including painting, kitchen, bathroom, and laundry upgrades at Lot 39 Bani Street, Mabuiag Internal works, internal painting, external painting, kitchen upgrade, bathroom upgrade, laundry upgrade
AI helper
RFQ **** for internal works (painting, kitchen, bathroom, laundry) at Lot 39 Bani Street, Mabuiag. Lump sum price breakdown schedule required; non-conforming if amended. Quotation validity 90 days. Payment lump sum on completion, progress claims considered. Defect liability 12 months. Public liability insurance $20,000,000. Site access requires land council permits. Works during 8am-5pm. Submit via vendor panel or email by 18 Nov 2026 2pm.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice
The contractor warrants the works will be free from defects, comply with standards, and be fit for purpose. the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose
Best value for money, assessing quoted price and non-price criteria. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome
All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified
RFQ will be non-conforming if schedules are not completed or amended. if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non-conforming
CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
Design and construction of building+refurbishment+tenders+procurement+opportunities+61212&idLj=tw0rmW" style="text-decoration: underline; color: var(--color_text_heading); text-underline-offset: 2px;" title="Building Refurbishment Tenders" >refurbishment works to Shop 11, meeting room, within the heritage Campbell' s Corner building Refurbishment works to Shop 11, meeting room, heritage building renovation, design and construction services
AI helper
Muswellbrook Shire Council seeks submissions for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** closes 19 November 2026. Working hours 7am-5pm Monday to Friday. Liquidated damages $100 per day. Defects liability period 12 months. Public liability insurance $20 million required. Security: bank guarantees each 2. 5% of contract sum. Payment claims by 28th day of each month. Indigenous participation target applies.
Payment claims are made progressively, with the principal paying the scheduled amount within 15 business days after receiving the claim. The contract states: the principal must pay the contractor the scheduled amount if any by the date that is 15 business days after the principals representatives receipt of the relevant payment claim.
The contractor warrants that all materials and equipment supplied will be new, fit for purpose, and comply with the National Construction Code. The contract states: all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code.
The contractor must be appropriately qualified and experienced. The contract states: seeking submissions from appropriately qualified and experienced respondents for the design and construction of the refurbishment works.
Liquidated damages of $100 per day apply for late completion. The contract states: liquidated damages will be due and payable to the principal by the contractor at the rate stated in item 17 which is $100 per day.
Failure to provide security within 3 business days after the contract date may result in default. The contract states: the contractor must, within 3 business days after the contract date, provide such guarantees to the principals representative.
Building Renovation/ Interior Fitout/ Kitchen Renovation/ Bathroom Renovation/ Laundry Renovation
****- ****- Lot 39 Bani Street, Mabuiag ( Int Works/Painting/Kitchen/Bahroom/Laundry) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refe
Internal works including painting, kitchen, bathroom, and laundry upgrades at Lot 39 Bani Street, Mabuiag Internal painting, external painting, kitchen upgrade, bathroom upgrade, laundry upgrade, internal works, site works, WHS, freight, travel, accommodation, compliance, waste disposal
AI helper
RFQ **** for internal works (painting, kitchen, bathroom, laundry) at Lot 39 Bani Street, Mabuiag. Lump sum price breakdown schedule required; non-conforming if amended. Quotation validity 90 days. Payment lump sum on completion, progress claims considered. Defect liability 12 months. Public liability insurance $20,000,000. Site access requires land council permits. Works during 8am-5pm. Evaluation: local content 15%, price 45%, quality 15%, WHS 10%, schedule 15%. Submit via vendor panel or email.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.
The contractor warrants the works will be free from defects and fit for purpose. the contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.
The engagement shall be awarded to the respondent who best demonstrates best value for money. the engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.
All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified.
If the quotation form and response schedules are not completed, the RFQ will be non-conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming ( items 7. 1 through to 7. 8)
CAMPBELLS CORNER - SHOP 11 MAYORS OFFICE RENOVATION - Muswellbrook Shire Council ( MSC) is seeking submissions from appropriately qualified and experienced Respondents for the design and construction of the refurbishment works to Shop 11, Meeting Room, within the heritage Campbell' s Corner building. Request for Quotation Closing Time and Lodgement Details
Design and construction of refurbishment works to Shop 11, meeting room, within the heritage Campbell' s Corner building Refurbishment works to Shop 11, meeting room, heritage building renovation, design and construction services
AI helper
Muswellbrook Shire Council seeks submissions for design and construction of refurbishment works to Shop 11, meeting room, within heritage Campbell's Corner building. Contract **** closes 19 November 2026. Working hours 7am-5pm Monday to Friday. Liquidated damages $100 per day. Defects liability period 12 months. Public liability insurance $20 million. Security: bank guarantees each 2. 5% of contract sum, retention 10% of each payment until 5% retained. Payment claims by 28th day of each month. Indigenous participation target applies.
The contractor must claim payment progressively, with payment claims due on the 28th day of each month. The principal pays the scheduled amount within 15 business days after receiving the payment claim. time for payment claims 28th day of each month
The contractor warrants that all material and equipment supplied will be new, fit for purpose, and comply with the National Construction Code. all material and equipment it supplies under this contract will be new unless the principal agrees otherwise in writing, fit for purpose and comply with the national construction code
Liquidated damages are $100 per day if the works do not reach completion by the date for completion. liquidated damages rate 100 per day
Building Renovation/ Interior Fitout/ Kitchen Renovation/ Bathroom Renovation/ Laundry Renovation
****- ****- Lot 39 Bani Street, Mabuiag ( Int Works/Painting/Kitchen/Bahroom/Laundry) - Please complete " 7. 3 Lump Sum Price Breakdown Schedule" If the line breakdowns for the " 7. 3 Lump Sum Price Breakdown Schedule" have been amended the RFQ will be classed as non- conforming. If the quotation form and Response Schedules are not completed the RFQ will be classed as non- conforming ( Items 7. 1 through to 7. 8) All Specifications etc are attached for download. JOB SUMMARY GUIDELINES Please refe
Internal works including painting, kitchen, bathroom, and laundry upgrades at Lot 39 Bani Street, Mabuiag Internal works, internal painting, external painting, kitchen upgrade, bathroom upgrade, laundry upgrade
AI helper
RFQ for internal works including painting, kitchen, bathroom, and laundry upgrades at Lot 39 Bani Street, Mabuiag. Lump sum price breakdown required; non-conforming if incomplete. Evaluation based on best value for money with weightings: local content 15%, price 45%, quality 15%, WHS 10%, schedule 15%. Payment within 30 days of valid invoice. Defect liability 12 months. Public liability insurance $20M required. Site access requires land council permits. Quotation validity 90 days.
The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.
The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome for the principal.
All work must be carried out by experienced and licensed personnel in the field of work specified.
if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
