The tender invites quotations for the supply and construction of a new sewer rising main at Texas Apex Park, including underbore and connection to the existing gravity sewer network. Closing is **** 4?pm EST. Evaluation considers price, past performance, technical expertise, WHS systems, availability and local contractor status. Payment is 80?% upon progress, 20?% on completion. 12?month workmanship warranty applies.
The tender closes at 4:00 pm EST on 30 October 2026. tender closing time of 4:00 pm est, friday 30th october 2026.
Payments are 80?% of the contract sum upon completion of works, with the remaining 20?% payable on completion. council will make payments for completed works up to a maximum of 80 of the contract sum until the works are completed.
12?month workmanship warranty from practical completion. 12 months warranty on all workmanship from the date of the practical completion inspection.
Evaluation on tendered prices, past performance, technical expertise, WHS systems, availability, and local contractor. tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.
Contractors must be suitably qualified, experienced and resourced. suitably qualified, experienced and resourced contractors.
No mandatory site visit; requests are welcome. there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.
Direct contact outside approved channel leads to automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification.
