Form Guide Tenders

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money.

All work must be carried out by experienced and licensed personnel in the field of work specified.

attendance at site inspection na

if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants the works will be free from defects, comply with standards, and be fit for purpose. the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose

Best value for money, assessing quoted price and non-price criteria. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome

All work must be carried out by experienced and licensed personnel. all work must be carried out by experienced and licensed personnel in the field of work specified

RFQ will be non-conforming if schedules are not completed. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice. the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice

The contractor warrants works are free from defects, comply with standards, and are fit for purpose. the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose

Best value for money, assessing price and non-price criteria. awarded to the respondent who best demonstrates the ability to provide best value for money

RFQ classed as non-conforming if schedules not completed. if the quotation form and response schedules are not completed the rfq will be classed as non-conforming

Payment is lump sum on completion and the contractor will be paid by tsirc within 30 days of receiving a valid tax invoice.

Defect liability period is 12 months from completion date and contractor must remedy defects within 30 days of being notified by tsirc.

The engagement shall be awarded to the respondent who best demonstrates the ability to provide best value for money with price and non-price criteria assessed together.

All work must be carried out by experienced and licensed personnel in the field of work specified and contractor must hold appropriate insurances including public liability.

If the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non-conforming and incomplete quotation forms also non-conforming.

The contractor will be paid by tsirc within 30 days of receiving a valid tax invoice including breakdown of rates, materials, travel, accommodation and any other information requested or required under the contract.

The contractor warrants that, when title of the works passes to tsirc, the works will: be free from any charge, liability or defect comply with all applicable standards be fit for purpose and conform to the description ordered.

The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money. the quoted price and relevant nonprice criteria will be assessed together to determine the most advantageous outcome for the principal.

All work must be carried out by experienced and licensed personnel in the field of work specified.

if the line breakdowns for the 7. 3 lump sum price breakdown schedule have been amended the rfq will be classed as non- conforming. if the quotation form and response schedules are not completed the rfq will be classed as non- conforming