Sewerage System Tenders

closing time of 4pm est, friday 30th october 2026.

payments for completed works up to a maximum of 80% of the contract sum until the works are completed.

12 months warranty on all workmanship from the date of the practical completion inspection.

tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

suitably qualified, experienced and resourced contractors.

failure to maintain progress in accordance with the approved project schedule. . . may result in the application of liquidated damages.

there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

supplier query cutoff friday 30 october 2026 03:00 am e. south america standard time.

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification.

tender closing openingsubmissions shall be lodged on or before the closing time of 4pm est, friday 30th october 2026.

council will make payments for completed works up to a maximum of 80 of the contract sum until the works are completed. the remaining 20 of the contract sum will become payable upon completion of the works and submission and acceptance of the following: full construction of the rising main and connection to the manhole completion and passing of all specified pipeline testing as constructed plans final rehabilitation of all work and laydown areas in accordance with the contract requirements completion of any other outstanding works, rectification of defects or other requirements necessary to achieve completion of the works.

the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

submissions will be assessed on the following criteria: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

goondiwindi regional council invites quotations from suitably qualified, experienced and resourced contractors for the supply and construction of the sewer rising main.

there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

supplier query cutoff friday 30 october 2026 03:00 am e. south america standard time.

The submission deadline is 13 October 2026 at 03:00 am. closes Tuesday 13 October 2026 03: 00 am e. south america standard time

tender closing on: 15 October 2026 12: 00 am e. south america standard time

there will be no mandatory site inspection for this tender

clarification and questions close: 8 october 2026

tender submissions shall be lodged on or before the closing time of 4pm est, friday 30th october 2026.

council will make payments for completed works up to a maximum of 80 of the contract sum until the works are completed.

contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

evaluation criteria: tendered prices, past performance, suitability of technical expertise, contractor WHS systems, availability, local contractor.

contractor must be suitably qualified, experienced, and resourced.

there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

supplier query cutoff friday 30 october 2026 03:00 am e. south america standard time

any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.