Stage 2 Woodriff Lane Creative Lighting Project - Artistic Overlay - Stage 2 of the project seeks to design, fabricate and install a new artistic overlay retrofitted onto four ( 4) existing light pole frames in Woodriff Lane. The scope of works for delivery are as follows: - Assess and review the existing light pole frames and lighting infrastructure in Woodriff Lane. - Design an artistic overlay which is functional and works with the newly upgraded lighting infrastructure. The design should consider a con
Design, fabrication and installation of artistic overlays retrofitted onto four existing light pole frames in Woodriff Lane Artistic overlay design, Artistic overlay fabrication, Artistic overlay installation, User and maintenance manual
AI helper
Stage 2 of the Woodriff Lane Creative Lighting Project involves designing, fabricating, and installing artistic overlays on four existing light pole frames. The contractor must assess existing infrastructure, design a functional artistic overlay, fabricate four overlays with a lifespan of 5+ years, integrate with RGBW lighting, install them, and provide a maintenance manual. Engagement of a local artist from Penrith LGA or Western Sydney is encouraged. Tender closes 24 November 2026.
Payment is made according to the contract particulars, either as a single payment 14 days after practical completion or multiple progress payments. The contract states: if a single payment is applicable, 14 days after practical completion.
The contractor must obtain and provide the benefit of all reasonably commercially available warranties. The contract states: the contractor must obtain and provide to the principal the benefit of all reasonably commercially available warranties provided for works similar to the works.
The contractor must be suitably qualified and experienced. The contract states: the contractor warrants to the principal that the contractor at all times shall be suitably qualified and experienced and shall exercise due skill, care and diligence in the execution and completion of the works.
Liquidated damages apply if practical completion is not achieved by the due date. The contract states: if practical completion is not achieved by the date for practical completion, the contractor must pay liquidated damages for delay in completing the works.
Failure to comply with directions or provide required documents may constitute a substantial breach. The contract states: a failure by the contractor to provide a contractors program or comply with any direction of the principal under this clause 13 shall be a substantial breach of contract for the purpose of clause 23.
EOI - Art and Light Installations for NarraBRIGHT 2027 - Narrabri Shire Council is inviting Expressions of Interest ( EOI) from artists and creatives for art and light installations for our annual NarraBRIGHT event, with the 2027 theme of Nature. Proudly presented by Narrabri Shire Council, NarraBRIGHT is a dynamic light and street festival that celebrates the vibrancy of our community, local businesses and town centre. Since its inception, NarraBRIGHT has grown into a signature event, attracting large audi
art and light installations permanent, semi- permanent, temporary art and light installations including projection lighting, interactive displays, and other creative installations
AI helper
Expression of Interest for art and light installations for Narrabright 2027. Deadline 21 Oct 2026 5:00pm. Event at Narrabri Creek Parklands, 8,000 attendees, alcohol?free. Submit brief description, technical requirements, portfolio, experience, contact details. Must hold public liability insurance of at least $20 million and relevant permits.
The EOI closes at 5:00pm on 21 October 2026. eoi closes: 5: 00pm wednesday, 21st october 2026
Must hold public liability insurance of at least $20 million. businessorganisation will supply relevant permits, licenses and have a current public liability insurance certificate of currency minimum policy 20 million
Disqualification if canvassing council staff. the canvassing of narrabri shire councillors or staff, at any time, in respect of this eoi will disqualify an entity submitting a quotation.
Department of Education - North Albany Senior High School - Percent for Art Project - New classroom block and Administration building - - Department of Education - North Albany Senior High School - Percent for Art Project - New classroom block and Administration building. Expression of Interest Artistic Services for Public Art.
Artistic services for public art Artistic services for public art for a new classroom block and administration building at North Albany Senior High School.
AI helper
Expression of Interest for artistic services for public art for the new classroom block and administration building at Department of Education North Albany Senior High School. Responses close on Thursday, 15 October 2026 at 2:30pm. Specification documents are available for download.
Department of Education - Champion Bay Senior High School - Artistic Services for Public Art - New Sports Hall - - Department of Education - Champion Bay Senior High School - Artistic Services for Public Art - New Sports Hall
Artistic services for public art Artistic services for public art for new sports hall
AI helper
Expression of Interest for artistic services for public art for the new sports hall at Champion Bay Senior High School. Responses close on Friday, 23 Oct 2026 at 2:30pm. Specification documents are available for download.
North St Marys Art for Playspace Upgrades - The Artist will be responsible for: o Consultation with Council' s Project Team and incorporating feedback as required. o Capturing and including Darug culture and knowledge in the artwork* o The artist/s need to abide by Indigenous Cultural and Intellectual Property ( ICIP) Principles, as outlined in best practice Federal Government Creative Australia ICIP Protocols and which have been consolidated for delivering public art in Penrith LGA. o Developing artistic
Artworks for playspace upgrades Artworks for two upcoming playground renewal projects in North St Marys.
AI helper
Penrith City Council seeks a First Nations artist or partnership to design and create new artworks for two playground renewal projects in North St Marys. The process is a two-stage EOI. Stage 1 shortlists 4 artists. Shortlisted artists receive **** excl. GST for concept development in Stage 2. Artists must incorporate Darug culture/knowledge, abide by ICIP principles, and manage fabrication/installation. EOI closing date is **** site briefing is scheduled for ****.
Payment terms are 30 days from the date of invoice. payment terms 30 days from the date of invoice
The evaluation will be based on whether the eoi satisfies the conditions of participation and the compliance criteria, followed by weighted qualitative evaluation criteria. eois will be assessed based on whether the eoi satisfies the conditions of participation in clause b6 and the compliance criteria
Respondents must demonstrate eligibility, including First Nations or First Nationsled collaborations, and complete all required EOI schedules. artist eligibility: demonstrate you fulfill the eligibility requirements for this project, including first nations or first nationsled collaborations
A site briefing is scheduled for Monday 24th August 2026 at 2:30pm at Robin Wiles Park Maple Rd, North St Marys. site briefing monday 24th august 2026 at 2: 30pm
An eoi may be excluded if the respondent is insolvent, incomplete, or fails to comply with EOI conditions. any eoi may be regarded as nonconforming and excluded from further participation if: the respondent is or becomes insolvent, bankrupt or subject to external administration
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
