**** - Construction of 2025 & 2026 DRFA Program - Tenders are invited to establish a Schedule of Rates Contract in accordance with ****: ****, for the engagement of a suitably qualified civil construction contractor to deliver the approved flood damage reconstruction works to the Gympie Regional Council local road network. Tenders will be accepted from contractors with TMR prequalification of R2/F50.
Construction of 2025 & 2026 DRFA program - flood damage reconstruction works to Gympie Regional Council local road network Schedule of rates contract for civil construction works including pavements, drainage and roadside furniture on sealed and unsealed road network; two packages of work located in eastern and western areas across Gympie Regional Council area
AI helper
Tenders invited for schedule of rates contract under AS4000:1997 for flood damage reconstruction works to Gympie Regional Council local road network. Contract includes two packages (eastern and western areas). TMR prequalification R2/F50 mandatory. Closing date 2pm Thursday 15 October 2026. Practical completion by 17 December 2027, with possible extension to 30 March 2028. Post-construction evidence due within 3 months of practical completion. Evaluation criteria include price (20%), experience/capacity (40%), methodology (20%), quality management (15%), health and safety (10%), environment and sustainability (5%), local benefits (10%). Tenders submitted electronically via VendorPanel. Clarification cutoff 5 working days before closing.
The final date for practical completion for both packages of work is 17 December 2027, with possible extension to 30 March 2028. As stated: the contract will be established with a final date for practical completion for both packages of work of 17 december 2027.
The evaluation methodology combines price and nonprice scores to calculate a best value index. As stated: the results of the price and nonprice evaluation are then combined to calculate a best value index bvi for each tenderer.
Tenders will only be accepted from contractors with TMR prequalification of R2/F50. As stated: tenders will be accepted from contractors with tmr prequalification of r2f50.
Clarifications cutoff is five working days prior to closing date. As stated: cutoff for requests for clarification or further information is five 5 working days prior to the closing date.
Prohibited contact with council members or employees may result in disqualification. As stated: any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
**** - Construction of 2025 & 2026 DRFA Program - Tenders are invited to establish a Schedule of Rates Contract in accordance with ****: ****, for the engagement of a suitably qualified civil construction contractor to deliver the approved flood damage reconstruction works to the Gympie Regional Council local road network. Tenders will be accepted from contractors with TMR prequalification of R2/F50.
Construction of 2025 & 2026 DRFA program - flood damage reconstruction works to Gympie Regional Council local road network Reconstruction of public assets damaged by declared disaster events in 2025 and 2026; works on sealed and unsealed road network including pavements, drainage and roadside furniture; two packages of work located within eastern area and western area across Gympie Regional Council area
AI helper
Tenders invited for schedule of rates contract under AS4000:1997 for flood damage reconstruction works to Gympie Regional Council local road network. Contract includes two packages (eastern and western areas). TMR prequalification R2/F50 mandatory. Tenders close 2pm Thursday 15 October 2026. Practical completion by 17 December 2027, with possible extension to 30 March 2028. Post-construction evidence due within 3 months of practical completion. Evaluation criteria include price (20%), experience/capacity (40%), methodology (20%), quality (15%), health/safety (10%), environment/sustainability (5%), local benefits (10%). Submissions via VendorPanel portal. Clarification cutoff 5 working days before closing.
The final date for practical completion for both packages is 17 December 2027, with possible extension to 30 March 2028. The contract will be established with a final date for practical completion for both packages of work of 17 december 2027.
The evaluation methodology combines price and nonprice scores to calculate a best value index. The results of the price and nonprice evaluation are then combined to calculate a best value index bvi for each tenderer.
Tenders accepted only from contractors with TMR prequalification of R2/F50. Tenders will be accepted from contractors with tmr prequalification of r2f50.
Clarifications cutoff is five working days prior to closing date. Clarifications cutoff for requests for clarification or further information is five 5 working days prior to the closing date.
Prohibited contact with council members or employees may result in disqualification. Any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
Filter tenders, save promising opportunities and ask questions about tender documents.
Filters and map
Filter by location, procurement type and value. View opportunities on the map to decide what deserves a closer look.
Favourites and notes
Save the tenders that interest you and add private notes, so you can return to your review later.
Tender document assistant
Ask questions about documents the system can read. Check the answers against the tender documents and the official source.
Frequently asked questions
It is a government tender search service for Australia. Find opportunities related to what your business supplies, keep separate searches organised and receive email alerts.
Start with your email. Then add specific products or services and the locations you want to search. Your first monitoring group is created automatically, so you can get started without setting everything up.
No credit card is required and there are no automatic charges. Try the service for 14 days and choose a paid plan only if you decide to continue.
As soon as you save what you supply and your preferred locations, you can see matching tenders on the site. Start with that list and explore filters and other tools at your own pace.
Official portals remain the source for checking notices and documents. BidHits combines smart search, state and territory filters, groups and alerts to help you shortlist tenders before opening each notice. Try it with your own products and compare it with your current routine.
They are separate searches for different parts of your business. You could have one called Well-equipped workplaces and another called New opportunities in Victoria, each with its own products, services and locations. You choose the names. The number of groups depends on your trial or plan.
Every plan includes email alerts. The Essential plan sends alerts directly to your main email. The Professional and Advanced plans let you group email addresses into lists, such as Sales and Purchasing, then choose which list receives alerts from each monitoring group. Groups define what to track; lists define who receives it. Several groups can use the same list. List and additional email limits apply to the whole plan, not separately to each group or list.
Alerts send matching tenders to your registered email according to the schedule available in your trial or plan. You can adjust email settings. Results appear on the site after you save your products and locations; emails follow the sending schedule. Where several daily sending times are available, the schedule applies across all groups and lists.
Use specific product or service names, such as office chairs. Smart search helps connect your offer with other descriptions, such as pest control and insect and rodent management. AI can make mistakes: check whether each opportunity is relevant and adjust your search terms when needed.
Filter by location, procurement type, dates and values, view opportunities on the map and save relevant tenders as favourites. Add private notes so you can pick up your review later.
Yes. The AI assistant answers questions about documents the system can read, within the question limit for your trial or plan. It supports your review; check the answers against the tender documents and the official source.
Look for the document or official notice link in the opportunity. If the source portal requires a login or restricts direct access, you may need to open the procurement page and download the documents there.
If you do not choose a paid plan, the tender list becomes limited. Nothing is charged automatically. You decide whether to subscribe and continue with the features of your chosen plan.
Human support is available for questions about access, searches, monitoring groups and settings. Start with the basics and explore other tools at your own pace.
Yes. The API is included in the Professional and Advanced plans, with one key per account and a separate API request allowance shared across its sessions. See the API documentation.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
