Generator tender - Estimated 5- year contract for Generator Servicing & Diesel Tank Inspections throughout the Torres and Cape Hospital and Health Service. seeking to establish a Service Agreement for the provision of Preventative, Corrective Maintenance of Generators and Diesel Generator Power Plant equipment operated and located at Torres and Cape Hospital and Health Service facilities. The Torres and Cape Hospital and Health Service own and operate a range of Generators and Diesel Generator Power Plant E
Generator servicing and diesel tank inspections Generator servicing, diesel tank inspections, preventative maintenance, corrective maintenance of generators and diesel generator power plant equipment
AI helper
This is an estimated 5-year contract for generator servicing and diesel tank inspections for Torres and Cape Hospital and Health Service. The service agreement covers preventative and corrective maintenance of generators and diesel generator power plant equipment. Maintenance must adhere to legislative requirements, Australian standards, and manufacturer recommendations. Corrective maintenance includes 24-hour, 7 days per week support. The estimated value is between 1M and 3M.
The maintenance provider must provide evidence to the satisfaction of the owners representative that staff performing the services have sufficient experience and expertise in this field to competently carry out the services required. the maintenance provider must provide evidence to the satisfaction of the owners representative that staff performing the services have sufficient experience and expertise in this field to competently carry out the services required.
Building And Facility Construction And Maintenance Services
D& R Airconditioning Supply and Install- Port Pirie Regional Council invites submissions for the replacement of the air conditioning system servicing the Development and Regulation ( D& R) Section of the Main Administration Building, located at 115 Ellen Street, Port Pirie SA ****, as detailed in this Request for Tender ( RFT). The works comprise the removal of the existing air conditioning system and the supply and installation of a replacement system in accordance with the design and specifications contai
Air conditioning system replacement Removal and disposal of existing air conditioning system; supply, installation, and commissioning of a new air conditioning system.
AI helper
The Port Pirie Regional Council invites tenders for the removal of the existing air conditioning system and the supply and installation of a replacement system at the main administration building (DR section). The closing date is 15 October 2026 at 2:00 pm Adelaide time. Tenderers must undertake a site inspection prior to submission, which must be arranged before 8 October 2026. The evaluation uses a weighted point score system considering price and non-price criteria. The preferred completion date is 15 January 2027.
The council must pay to the contractor, within thirty 30 days of the end of the month in which the practical certificate is issued, the agreed sum as adjusted by this agreement.
The defects liability period for the works commences upon practical completion of the works and continues until expiry of the period stated in item 8 of the schedule.
The evaluation panel will use a weighted point score evaluation system that allows price and nonprice criteria to be taken into account in the selection of a preferred tenderer.
Each tenderer must if applicable be licensed or registered to perform the services.
If the works do not reach practical completion by the date for practical completion, and no extension of time has been granted, liquidated damages will be due and payable to the council as set out in item 17 for every day after twentyone 21 days from the date for practical completion to and including the earliest of the date of practical completion or termination of this agreement or the council taking all remaining works out of the hands of the contractor.
Site inspections tenderers are encouraged to undertake a site inspection prior to submitting a tender. site visits may be arranged by contacting alan bennett.
Park Maintenance/ Building And Facility Construction And Maintenance Services/ Structures And Building And Construction And Manufacturing Components And Supplies
T2026/0066 - South Park Lands Creek - Reach 7, Park 19- Open Channel Rehabilitation in Park 19, East of Unley Road ( Reach 7) in line with the Water Infrastructure Asset Management Plan. Works consist of reshaping and rehabilitating the open channel and restoring condition to as new.
Open channel rehabilitation Open channel rehabilitation in Park 19, east of Unley Road ( Reach 7)
AI helper
The City of Adelaide invites tenders for open channel rehabilitation in Park 19, east of Unley Road (Reach 7), as per the water infrastructure asset management plan. Works involve reshaping and rehabilitating the open channel to as new condition. Tender closes at 5:00 pm on 28 September 2026. Specification documents are available for download.
25/26- 540 Urban Forest Tree Planting - The City of Ballarat will provide a list of selected locations where the planting of trees is to occur. The contractor will be responsible for the sourcing and purchasing of all trees required as part of this contract. The contractor is required to determine the appropriate planting configuration using provided guidelines. Maintenance includes watering, weeding, pruning, insect/pathogen control, stake and tie replacement as required and reporting any loss/death of
Urban forest tree planting Supply, planting, and ongoing maintenance of trees for the urban forest tree planting program.
AI helper
The contractor is responsible for sourcing, purchasing, planting, and maintaining trees for 3 years (with options for extension). Planting must occur in two periods: July to October and April to June. Maintenance includes watering, weeding, pruning, and pest control. A two-year warranty applies from the planting date. Penalties may apply for more than 5 tree losses per season. Electronic recording using the city's asset management system is required.
The first planting period must have all trees planted by mid-October, and the second period by June 30, unless directed otherwise. the first period shall commence on 1 july, with all trees to be planted by midoctober.
Payment will be made upon submission of tax invoices by the contractor, in accordance with council's payment policies. payment for services or works will be made by the principal on submission of tax invoices by the contractor
The warranty period for this contract is two years, commencing from the date the tree is planted. the warranty period for this contract is two years.
Staff must be suitably trained and qualified, with at least one employee holding a Certificate III Horticulture. at a minimum, the contractor shall provide an employee who is qualified with a certificate iii horticulture
Penalties may apply if a greater than 5 loss of trees, per season, is experienced. penalties may apply if a greater than 5 loss of trees, per season, is experienced.
The supplier query cutoff is Thursday, October 1, 2026, 01:00 am E. South America Standard Time. supplier query cutoff thursday 01 october 2026 01: 00 am e. south america standard time
External Building Maintenance/ Painting Supplies Services/ Building Maintenance Services
Tully Civic Centre External Building Remediation, Repainting and Signage Works - Cassowary Coast Regional Council is seeking quotations from suitably qualified contractors for the **** - Tully Civic Centre External Building Remediation, Repainting and Signage Works located at 34- 40 Bryant Street, Tully QLD 4854. The Works generally include external building remediation and repainting works, scaffolding and access requirements, removal and installation of signage, cleaning and preparation of external surf
External building remediation, repainting and signage works External building remediation, repainting, scaffolding, access requirements, signage removal and installation, cleaning and preparation of external surfaces.
AI helper
Cassowary Coast Regional Council seeks quotations for external building remediation, repainting, and signage works at Tully Civic Centre. The works include remediation, repainting, scaffolding, signage removal/installation, and surface preparation. A mandatory site inspection is held on 23/09/2026. Quotations must be submitted via VendorPanel by 01/10/2026 17:00 AEST. Evaluation criteria include price (30%), program (25%), methodology (25%), experience (10%), and local content (10%). The works must be completed by 31/05/2027. If Dulux paint is used, notification to Dulux is required at least 7 days prior to commencement.
The works must be completed by 31 May 2027.
Respondents must provide all required warranties, manuals, product information and handover documentation for practical completion.
Evaluation criteria weighting price 30 program 25 methodology 25 experience 10 local content 10.
Respondents are required to submit a proposed program for the works.
A site inspection is held at **** Bryant Street Tully on Wednesday 23rd September 2026 at 10:00am.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I liked the way they search for tenders and provide us with the link to view them.
C. J. P. Perez
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
It encompasses all portals in one place.
G. Ferrea
A very good platform.
D. C. Espinosa
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
It’s one of the best platforms for searching bids.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
