Bushfire Hazard Tree Removal - Mount Alexander Shire Council ( MASC) incurred significant damage to trees during the January 2026 Harcourt and District bushfires with a high number of hazard trees assessed and removed within the initial MASC Disaster Response. A secondary assessment of roadside hazard trees undertaken by MASC in August 2026 identified many of the retained trees impacted by the fire event are dead/unviable/hazardous with appropriate works programmed. Online Tenderer Information Session ( N
Bushfire hazard tree removal and transportation of logwood Removal of 280 fire- affected hazard trees, including deadwood removal and stem removal reduction, and transportation of logwood generated from tree works to Castlemaine transfer station or other suitable locations.
AI helper
Council seeks contractors for emergency hazard tree removal and logwood transportation following bushfires. Works must commence on **** and be completed by **** close on **** at 2pm. Evaluation is based on a weighted score combining qualitative assessment (100 points) and cost (VFM). Detailed invoices requiring embedded photographs are necessary for federal funding claims. An online tenderer information session is available on ****.
All works must commence on Monday 12 October 2026 and be complete by Friday 13th November 2026. all works must commence on monday 12 october 2026 and be complete by friday 13th november 2026.
Payment is made within 21 business days after the invoice has been approved by the authorised representative of the principal. 21 business days after invoice has been approved by the authorised representative of the principal.
Tenders will be evaluated on a weighted score where the aim is to have a lower price and a higher stage one score, meaning the lowest result is the best value for money. to be the successful tenderer, the aim is to have a lower price and a higher stage one score, meaning the lowest result is the best value for money.
Tenders are assessed on risk management, OH&S system, public liability insurance (20 million), workcover insurance, response to scope of works, experience, and business capacity. stage one qualitative assessment of a weighted score totalling 100
If the contractor fails to reach practical completion by the date for practical completion, liquidated damages will apply at the rate stated in the covering page for every day after. if the contractor fails to reach practical completion by the date for practical completion, the contractor will be immediately indebted to the principal for liquidated damages at the rate stated in the covering page for every day after the date for practical completion to and including the date of practical completion or the date that the contract is terminated, whichever first occurs.
Soliciting information outside the scope of contract or advantage in the procurement process from council officers or councillors will result in the tender being withdrawn. any submitter seeking information outside the scope of contract or advantage in the procurement process from council officers or councillors will have their tender withdrawn from the evaluation process.
DESIGN AND CONSTRUCT - BIRKDALE COMMUNITY PRECINCT ENABLING INFRASTRUCTURE AND LAGOON SUB- PRECINCT - Redland City Council invites suitably qualified and experienced Contractors to submit Expressions of Interest ( EOI) for the Design and Construct delivery of the Birkdale Community Precinct ( BCP) Enabling Works and Lagoon Precinct. Respondents may submit an EOI for one or both project components. Enabling Works generally comprise: Bulk earthworks and site preparation works. Internal roads and associated pa
Design and construct enabling infrastructure and lagoon precinct Enabling works: bulk earthworks, site preparation, internal roads, associated pavement construction, site entry intersection works, roundabout construction, car parks, bus laydown facilities, stormwater drainage, wetlands, bioretention, water quality infrastructure, water, sewer, fire, utility infrastructure, electrical, communications, high voltage reticulation, shared pathways, pedestrian infrastructure, landscaping, signage, wayfinding, and project interface management. Lagoon precinct: large- scale public swimming lagoon ( adult/children), interactive waterplay facilities, splash zones, 1, 518m two- storey pavilion ( restaurant, cafe, retail, function spaces), public plazas, outdoor BBQ facilities, two amenities buildings ( including DDA compliant changing places), plant rooms, water treatment infrastructure, and associated landscaping/public realm.
AI helper
Redland City Council seeks Expressions of Interest (EOI) for the design and construct delivery of the Birkdale Community Precinct (BCP) enabling works and the lagoon precinct. Respondents may bid for one or both components. Enabling works include earthworks, roads, utilities, and site preparation. The lagoon precinct involves a large public swimming lagoon and associated amenities. Submissions must be electronic by 5:00 pm on Wednesday, October 7, 2026. Evaluation is non-price based, considering capability, methodology, experience, and local business benefit. A subsequent RFP process will follow.
The EOI closing date is Wednesday, October 7, 2026, at 5:00 pm. closing date and time: 5: 00pm wednesday 7th october2026
Submissions will be evaluated against criteria including capability and capacity, methodology and approach, previous experience, and local business and benefit. eoi submissions will be evaluated against the following criteria that are scored and weighted criteria: o capability and capacity o methodology and approach o previous experience o local business and benefit
Respondents must have demonstrated capability in delivering large-scale civil or aquatic infrastructure under a design and construct model. identify contractors with demonstrated capability in delivering largescale civil infrastructure and/or largescale aquatic infrastructure projects under a design and construct delivery model
A respondent who directly or indirectly canvasses support from an elected member, employee or agent of council will be disqualified. respondent must not canvas support any respondent who directly or indirectly canvasses support from an elected member, employee or agent of council will be disqualified from the process
Essential Safety Measures for Fire & Access and Electrical Services - The City of Greater Bendigo invites tenders and submissions from suitably accredited and qualified Service Providers to provide under a Schedule of Rates arrangement, annual inspection servicing, reporting and advisory services to enable the City to be essential safety measures ( ESM) compliant for Public Buildings and other nominated occupancies that are the responsibility of the City. This is 3- year contract with an optional extension
Essential safety measures for fire & access and electrical services Annual inspection servicing, reporting and advisory services to enable the city to be essential safety measures ( esm) compliant for public buildings and other nominated occupancies.
AI helper
The City of Greater Bendigo invites tenders for a 3-year contract (with optional 2-year extension) for essential safety measures (ESM) compliance services for public buildings. Tender closing time is 22 September 2026 at 3pm AEST. A mandatory tender briefing is held on 07 September 2026. Evaluation includes weighted criteria covering capability, capacity, economic sustainability, and environmental/social sustainability. Tenderers must complete and submit specific response schedules and pricing documents electronically via VendorPanel.
Tenders will be evaluated and scored against weighted criteria including capability (30%), capacity (30%), economic sustainability (20%), and others (5% each).
Tenderers must comply with mandatory requirements, including registration or licensing if required by act, and must become an approved prequalified contractor if successful.
Failure to attend a mandatory briefing session may disqualify a tenderer, and failure to complete required documents will deem the submission nonconforming.
Fire Protection/ Fire Detection/ Fire Suppression/ Fire Hose Reels/ Fire Hydrants/ Fire Pump/ Fire Safety
Fire Protection Services - Parliamentary Precinct - The Queensland Parliamentary Service ( QPS) is calling for submissions from suitably qualified suppliers for the provision of routine inspections of fire protection systems and equipment and reactive maintenance at the Parliamentary Precinct
Fire protection services Routine inspection of fire protection systems and equipment and reactive maintenance at the parliamentary precinct.
AI helper
The Queensland Parliamentary Service (QPS) seeks submissions for routine inspections and reactive maintenance of fire protection systems at the parliamentary precinct. The contract term is initially three years with an option to extend for two 12-month periods. Offers must be lodged electronically by 25 September 2026 at 10am. Evaluation criteria include value for money, demonstrated experience, technical capability, service delivery, and local benefits. Payments will be monthly in arrears.
Payments made under a contract awarded from this tender will be monthly in arrears. the successful supplier accepts that payments made under a contract awarded from this tender will be monthly in arrears.
The contractor warrants that it complies with, and will continue to comply with, the Queensland government supplier code of conduct for the term of the proposed contract. does the contractor warrant that it complies with, and will continue to comply with, the queensland government supplier code of conduct
Submissions will be assessed using weighted criteria including value for money, demonstrated experience, technical capability, service delivery, and local benefits. weighted criteria 1. value for money 1. demonstrated experience with fire safety panels and systems 1. technical capability and resourcing 1. service delivery and response capability
A site meeting with tenderers will be available so that the full scope of works may be assessed and any queries may be clarified. a site meeting with tenderers will be available so that the full scope of works may be assessed and any queries may be clarified.
The customer may immediately disqualify a supplier that it believes has breached any warranty in this clause. in addition to any other remedies available to it under law or contract, the customer may, in its absolute discretion but is not required to, immediately disqualify a supplier that it believes has breached any warranty in this clause.
Bushfire Hazard Tree Removal - Mount Alexander Shire Council ( MASC) incurred significant damage to trees during the January 2026 Harcourt and District bushfires with a high number of hazard trees assessed and removed within the initial MASC Disaster Response. A secondary assessment of roadside hazard trees undertaken by MASC in August 2026 identified many of the retained trees impacted by the fire event are dead/unviable/hazardous with appropriate works programmed. Online Tenderer Information Session ( N
Bushfire hazard tree removal and transportation of logwood Removal of 280 fire- affected hazard trees, including deadwood removal and stem removal reduction, and transportation of logwood generated from tree works to Castlemaine transfer station or other suitable locations.
AI helper
Contractors are sought for emergency hazard tree removal and logwood transportation following bushfires. Works must commence on **** and be completed by **** close on **** at 2pm. Evaluation is based on a weighted score combining qualitative assessment (100 points) and quantitative cost assessment (VFM). Detailed invoices requiring embedded photographs are necessary for federal funding claims. An online tenderer information session is available on ****.
All works must commence on Monday 12 October 2026 and be complete by Friday 13th November 2026. all works must commence on monday 12 october 2026 and be complete by friday 13th november 2026.
Payment is made within 21 business days after the invoice has been approved by the authorised representative of the principal. 21 business days after invoice has been approved by the authorised representative of the principal.
Tenders will be evaluated on a weighted score aiming for the lowest price and a higher stage one score, meaning the lowest result is the best value for money. to be the successful tenderer, the aim is to have a lower price and a higher stage one score, meaning the lowest result is the best value for money.
Tenders are assessed on risk management, OHS system, public liability insurance (20 million), workcover insurance, response to scope of works, experience, and business capacity. stage one qualitative assessment of a weighted score totalling 100
Liquidated damages apply if the contractor fails to reach practical completion by the date for practical completion. if the contractor fails to reach practical completion by the date for practical completion, the contractor will be immediately indebted to the principal for liquidated damages at the rate stated in the covering page for every day after the date for practical completion to and including the date of practical completion or the date that the contract is terminated, whichever first occurs.
Failure to remedy a default within 5 business days, insolvency, or abandoning works may lead to contract termination. in the event that the contractor: a fails to remedy a default within 5 business days from the date of being notified of the default by the principal
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
It encompasses all portals in one place.
G. Ferrea
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Excellent information. Just what I was looking for.
L. H. Borrelli
Fast, flexible, and simple.
E. Disruptivas
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
They notify me promptly when a contest is published.
L. Salazar
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
I am very satisfied; it's a very useful tool.
J. S. Garcia
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I quickly find the tenders that interest me.
S. Roque
The idea of ​​using a keyword and sending the information by email is very good.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
