ITO - Network Hardware and Field Services - The procurement will establish a contemporary replacement arrangement to ensure continuity of network hardware supply, maintenance, support and lifecycle management across CITEC' s IP- VPN, Inter- Data Centre and Point- to- Point Optical Transport services. It will replace ageing infrastructure, introduce modern technologies and network management capabilities, and maintain a reliable, resilient and scalable network environment to meet CITEC and Queensland Governm
AI helper
This Invitation to Offer (ITO) seeks to establish a contract for network hardware supply, maintenance, support, and lifecycle management across Queensland. The contract is divided into four parts: network hardware, optical network infrastructure, breakfix replacement services, and other network equipment. The initial term is five years with three one-year extension options. Offers must be submitted electronically via VendorPanel by 23 November 2026. Suppliers must demonstrate a direct OEM relationship for parts A, B, and D. Evaluation considers capability, quality, cost, and compliance.
Offers must be received by the closing date and time. The closing date is 2pm 12th November 2026, as stated: closing date and time for offers 2pm 12th november 2026.
The contractor will manage warranty and maintenance arrangements associated with hardware requiring replacement or repair, including hardware purchased under the customer contract and hardware covered by existing warranty or maintenance arrangements.
The customer is not evaluating offers on the sole criterion of price. Criteria include capability and relevant experience, quality, and cost and value for money.
Suppliers must hold current OEM accreditation, authorisation or reseller/partner status and provide evidence of a direct contractual or commercial relationship with the OEM, as stated: hold current oem accreditation, authorisation or resellerpartner status.
Failure to maintain a direct OEM relationship during the contract period may be considered noncompliance and may impact eligibility, as stated: failure to maintain a direct oem relationship during the contract period may be a considered noncompliance.
RFT2027/5 Sewer Mains Maintenance ( Cootamundra) - Cootamundra- Gundagai Regional Council is seeking tenders from suitably qualified and experienced contractors for the provision of sewer mains maintenance services within Cootamundra. The services are required to support the ongoing operation, maintenance and reliability of Council' s sewer infrastructure network. Tenderers are invited to submit proposals in accordance with the tender documentation. - The Tenderer must familiarise with the Works and the Si
AI helper
Tenders from qualified contractors for sewer mains maintenance in Cootamundra, including cleaning, root cutting, CCTV inspection and smoke testing. No mandatory site inspection. Questions via vendor panel by 10 November 2026. Tender closes 17 November 2026. Contract period 30 calendar weeks. Liquidated damages **** per day. Retention 4% via bank guarantee. Payment claims monthly.
The time for completion is 30 calendar weeks after acceptance of the tender. the time for completion is: 30 calendar weeks after the date of acceptance of the tender.
Payment claims are made monthly, on and after the 25th day of each calendar month. a payment claim is to be made: monthly, on and after 25th day of each calendar month.
Tenderers must be suitably qualified and experienced contractors. seeking tenders from suitably qualified and experienced contractors for the provision of sewer mains maintenance services.
Liquidated damages are **** per day for late completion. the rate per day for liquidated damages is: ****
No mandatory site inspection will be held. no mandatory site inspection will be held for this tender.
R2Z3 Maintenance Grading - Central Highland Regional Council invites submissions from competent suppliers to supply all materials, plant, equipment, personnel and any other services, costs and/or fees necessary to: 1. Carry out full service maintenance work on the unsealed roads network within Zone 2. 3 ( Road specific information and zone information is detailed in Section 4).
AI helper
Central Highlands Regional Council invites submissions for full service maintenance grading of unsealed roads in Zone 2. 3. Contract type is lump sum schedule of rates. Closing date 12 November 2026 at 2:00 pm. Suppliers must provide all materials, plant, equipment, personnel and services. Contract includes general conditions, specific requirements, response schedules, and appendices. Security may be required. No subcontracting without approval. Payment subject to conditions in schedule 1.
Charging Network/ Charging Station Maintenance/ Infrastructure Maintenance Services
****- 2026 - EOI Provision, Installation & Operation of Electric Vehicle ( EV) Charging Infrastructure - Council is seeking Expressions of Interest ( EOI) from suitably qualified charge point operators ( CPOs) interested in installing, operating and maintaining public electric vehicle ( EV) charging infrastructure at Council- owned sites across the municipality. Council has identified eight potential sites for the installation of public EV charging infrastructure. Respondents may nominate one or more of the
Provision, installation and operation of electric vehicle ( EV) charging infrastructure Public EV charging infrastructure at eight council- owned sites: Hailes Street East Car Park, Watsonia Road Car Park, Greensborough War Memorial Park Car Park, Ford Park Car Park, Westley Avenue Car Park, Burton Crescent Car Park, Alma Road Car Park, Petrie Park Car Park
AI helper
Banyule City Council seeks EOIs from qualified charge point operators to install, operate and maintain public EV charging infrastructure at eight council-owned sites. Respondents may nominate one or more sites or propose alternatives. Successful respondents will fund, install, operate and maintain infrastructure and pay an annual fee per site. EOI closes 16 November 2026 at 3:00pm sharp. Submissions must be lodged electronically via the VendorPanel portal. Late submissions will be disqualified. EOI validity period is 120 days. Council will shortlist respondents for a subsequent RFT process.
EOIs received after the closing time will be disqualified. The document states: EOI received after the eoi closing time will be disqualified and ineligible for consideration.
**** Line Marking - Port Hedland Renewal Works - The Town of Port Hedland is seeking submissions from suitably experienced Contractors to undertake Line Marking on the Town of Port Hedland Road network, following road renewal works. Traffic Management and sweeping of the sites before commencing the line marking, will be the responsibility of the Contractor and must be included in its Lump Sum price. The Work sites that require line marking are: 1. Bell Street ( Wedgefield) 2. Richardson Drive ( Port H
Line marking services for road renewal works Line marking on Bell Street, Richardson Drive, Pinga Street intersections, Kennedy Street safety improvements, and Wedgefield Depot yard; includes traffic management, sweeping, and supply of line marking materials
AI helper
Line marking services for Port Hedland road network following renewal works. Contractor responsible for traffic management and site sweeping, included in lump sum price. Work sites include Bell Street, Richardson Drive, Pinga Street intersections, Kennedy Street, and Wedgefield Depot. Must comply with **** by 18 December 2026. Submissions online via VendorPanel by 13 November 2026, 16:00 WAST. Award based on best value for money, with qualitative criteria on relevant experience and capacity. Regional price preference may apply. Insurance requirements include public liability of $20 million and professional indemnity of $1 million.
The work is required to be completed by 18 December 2026, as stated: the work is required to be completed by the 18 december 2026.
Progress claims are to be issued upon completion of the project, as per the contract conditions: progress claims to be issued upon completion of project.
Defects liability period is 12 months from the date of practical completion, as stated: defects liability period 12 months from the date of practical completion.
The contract will be awarded based on best value for money, as stated: the principal has adopted the best value for money approach to this request.
Tenderers must demonstrate relevant experience and capacity to deliver resources, as stated: criteria relevant experience 50 capacity to deliver resources 50 total 100.
No site inspection is required, as stated: mandatory inspections na and briefing site inspection na.
Responses may be rejected if submitted after the deadline or not via VendorPanel, as stated: a response will be rejected without consideration of its merits in the event that: a. it is submitted after the deadline or b. it is not submitted at the place specified.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
Good information. All the information is very good!
We selected helpful reviews from real users. Order may change periodically.
It encompasses all portals in one place.
G. Ferrea
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
Excellent. More searches and many advantages.
R. Lopez
Everything is perfect. They are a great help in finding tenders relevant to our field of work. I really appreciate that the tenders are sent directly to my email; it’s a huge help in identifying where I can contribute and what I can do.
Oto
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
I like the way they provide information with the greatest possible accuracy. I love that.
M. A. Neil
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Excellent information. Just what I was looking for.
L. H. Borrelli
The tenders appear appropriately based on my interests.
V. Niembro
It is complete and optimal, it improves my time.
R. de L. Cruz
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
Smart search helped discover tenders I hadn't even imagined receiving notifications for.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 30.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1115 active users, conducted through 06/11/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
