Bus Shelter Advertising & Maintenance - Expression of Interest ( ****) - The City of West Torrens ( the Council) invites Expressions of Interest from Registrants for the provision of Bus Shelter Advertising and Maintenance in the City of West Torrens
Bus shelter advertising and maintenance Provision of bus shelter advertising and maintenance services, including potential replacement of select existing bus shelters, cleaning and maintenance of advertising and non- advertising shelters, immediate repairs and replacement of broken glass, panels, and seating, and proposal of revenue return through advertising.
AI helper
The City of West Torrens is seeking Expressions of Interest (EOI) for bus shelter advertising and maintenance services. The contract period is up to 5 years. Submissions are due by 2:00 PM on June 22, 2026. Key services include cleaning, maintenance, repairs, and potential replacement of bus shelters. Registrants must be registered and compliant in the Rapid Global contractor management system for WHS compliance. Evaluation criteria include insurance, WHS compliance, local supplier status, customer service experience, pricing, and risk assessment.
The EOI closing date is Monday, 22 June 2026, at 2:00 PM. eoi closing date: 2pm, 22 june 2026
Council payment terms are 30 days from the date of invoice. council payment terms are 30 days from date of invoice.
The council will consider insurance, WHS compliance, local supplier status, customer service experience and capacity, expression of interest prices, and the level of risk associated with contract negotiation.
Registrants must be licensed or registered to perform the services and must be registered and deemed compliant in the Rapid Global contractor management system for WHS compliance with the City of West Torrens.
Failure to lodge electronically, late submissions, or non-compliance with WHS registration requirements may lead to disqualification.
Bus Shelter Advertising & Maintenance - Expression of Interest ( ****) - The City of West Torrens ( the Council) invites Expressions of Interest from Registrants for the provision of Bus Shelter Advertising and Maintenance in the City of West Torrens
Bus shelter advertising and maintenance Provision of bus shelter advertising and maintenance services, including potential replacement of select existing bus shelters, cleaning and maintenance of advertising and non- advertising shelters, immediate repairs and replacement of broken glass, panels, and seating, and proposal of revenue return through advertising.
AI helper
The City of West Torrens is seeking Expressions of Interest (EOI) for bus shelter advertising and maintenance services. The contract period is up to 5 years. Submissions are due by 2:00 PM on June 22, 2026. Key services include cleaning, maintenance, repairs, and potential replacement of bus shelters. Registrants must be registered and compliant in the Rapid Global contractor management system for WHS compliance. Evaluation criteria include insurance, WHS compliance, local supplier status, customer service experience, pricing, and risk assessment.
The EOI closing date is 2:00 PM on Monday, 22 June 2026. eoi closing date: 2pm, 22 june 2026
Council payment terms are 30 days from the date of invoice. council payment terms are 30 days from date of invoice.
Evaluation criteria include insurance, compliance with work health and safety requirements, local supplier status, customer service experience and capacity, expression of interest prices, and the level of risk associated with negotiation of an acceptable contract.
Registrants must be licensed or registered to perform the services and must be registered and deemed compliant in the Rapid Global contractor management system for WHS compliance for the City of West Torrens. your organisation must be registered and deemed compliant in the rapid contractor manager module for the city of west torrens. this is a mandatory requirement.
The council may conduct a site/industry briefing, and registrants are not to treat any statements made at the briefing as variations to this REOI. he council may conduct a siteindustry briefing.
Failure to lodge electronically, late submissions, or failure to be registered and compliant in the Rapid Global system may result in disqualification. late expressions of interest expressions of interest received after the closing date will not be considered or accepted.
Real Festival 2026_ Event Infrastructure - Real Festival is Penrith City Council s annual flagship event, delivered at Tench Reserve along the Nepean River. The festival will be held on 11, 12 and 13 September 2026, bringing the community together to celebrate creativity, culture, sustainability, and the unique river environment that defines the region. As Penrith s largest family- focused event, Real Festival attracts thousands of visitors across its three- day program and features art installations, live
Event infrastructure for Real Festival 2026 and 2027 Supply, installation, servicing, and packdown of event structures, equipment, furnishings, crowd management solutions, and associated infrastructure. This includes site sheds, offices, parents room, toilets ( accessible and portable), handwash basins, temporary fencing, crowd control barriers, triton/waterfill barriers, scrim, buggy forks, knuckleboom lift, all- terrain scissor lifts, baby change tables, full- length mirrors, balloon lighting towers, and VMS boards.
AI helper
Penrith City Council is seeking a supplier for comprehensive event infrastructure for Real Festival 2026 and 2027. The scope includes supply, installation, servicing, and packdown of various event structures and equipment. The contract is for a two-year period. Respondents must submit a rates card and pricing for 2026, with an indicative estimate for 2027. A final walkthrough with the council's project lead is required. After-hours support and waste removal are also specified. References from similar projects are mandatory.
Bump in for infrastructure is scheduled for Tuesday 8 September 2026, with event readiness by 12:00 PM on Friday 11 September 2026. Bump out is scheduled for Monday 14 September 2026.
Suppliers must be suitably qualified and experienced, and submit two recent references from clients for whom they have completed work of a similar scale, scope, and operational requirements.
A site recce is recommended to confirm requirements, as event elements are subject to change. A final walkthrough with the council's project lead is mandatory.
Supplier query cutoff is Sunday 31 May 2026 at 11:00 PM E. South America Standard Time.
Real Festival 2026_ Event Infrastructure - Real Festival is Penrith City Council s annual flagship event, delivered at Tench Reserve along the Nepean River. The festival will be held on 11, 12 and 13 September 2026, bringing the community together to celebrate creativity, culture, sustainability, and the unique river environment that defines the region. As Penrith s largest family- focused event, Real Festival attracts thousands of visitors across its three- day program and features art installations, live
Event infrastructure for Real Festival 2026 and 2027 Supply, installation, servicing, and packdown of event structures, equipment, furnishings, crowd management solutions, and associated infrastructure. This includes site sheds, offices, parent' s room, toilets ( accessible and portable), handwash basins, temporary fencing, crowd control barriers, triton/waterfill barriers, scrim, buggy forks, knuckleboom lift, all- terrain scissor lifts, baby change tables, full- length mirrors, balloon lighting towers, and VMS boards.
AI helper
Penrith City Council is seeking a supplier for comprehensive event infrastructure for Real Festival 2026 and 2027. The scope includes supply, installation, servicing, and packdown of various event structures and equipment. The contract is for a two-year period. Respondents must submit a rates card and pricing for 2026, with an indicative estimate for 2027. The festival dates for 2026 are September **** site recce is recommended as event elements are subject to change. The successful respondent will be engaged for two years, subject to satisfactory performance. Faulty equipment must be immediately replaced, and after-hours support is required.
The event is scheduled for September 11, 12, and 13, 2026. Bump-in for infrastructure is scheduled for Tuesday, September 8, 2026, and bump-out is scheduled for Monday, September 14, 2026.
Suppliers are required to be suitably qualified and experienced and must provide wo recent references from clients for whom they have completed work of a similar scale, scope, and operational requirements.
A site recce is recommended to confirm requirements, as event elements are subject to change.
The supplier query cutoff is Sunday, May 31, 2026, 11:00 pm E. South America Standard Time.
**** Upgrades to Staff Housing 25- 26 - 1 INTRODUCTION The Central Highlands region is in Central Queensland, Australia. This region encompasses an area of around 60, 000 square kilometers, making it just short of the size of Tasmania. It is home to around 30, 000 people who live in the regional centers of Emerald ( approximately 15, 000 people) and twelve other unique communities being Arcadia Valley, Bauhinia, Blackwater, Bluff, Capella, Comet, Dingo, Duaringa, Rolleston, Gemfields, Springsure and Ti
Upgrades and repairs to staff housing Refurbishment works at 105 Burn Street, Capella, QLD, including internal repainting, flooring works, and window furnishings. Rectification of staff housing building defects and modification or renewal of building components at multiple council staff housing locations in Duaringa, Capella, and Blackwater.
AI helper
Central Highlands Regional Council is seeking a qualified building contractor for staff housing upgrades and repairs across multiple locations in Queensland. Works include repainting, flooring, window furnishings, and general building rectification. Tenderers must verify site conditions prior to pricing, as no variation claims will be accepted for failure to inspect. A 12-month defects liability period is required. The contract may be multi-awarded, and individual properties can be quoted separately. Compliance with Australian Standards and Work Health and Safety legislation is mandatory. A pre-start meeting will be held to confirm scope and obligations.
The tender closes on Friday, 12 June 2026, at 04:00 am E. South America Standard Time.
Tenderers shall allow for a twelve 12 month defects liability period dlp for each property from the date of practical completion. During the defects liability period, the contractor shall rectify any defects or workmanship issues identified by the principal within a reasonable timeframe and at no additional cost to the principal.
The council is seeking a qualified and experienced building contractor. The contractor and all subcontractors shall hold all relevant Queensland licences and competencies required for the works, including an appropriate QBCC licence where applicable. The successful principal contractor and subcontractors will need to complete a prequalification using the online induction system called LinkSafe.
Tenderers shall verify all dimensions, quantities, existing conditions and site constraints prior to pricing and commencement of works. No variation claims will be accepted for failure to inspect site conditions.
Supplier query cutoff is Wednesday, 10 June 2026, at 04:00 am E. South America Standard Time.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
90% recommend BidHits Australia (1058 real users, 08/06/2026).Methodology
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The tool is truly effective at scanning tender documents, efficiently delivering bids.
We selected helpful reviews from real users. Order may change periodically.
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
Excellent platform to help promote and expand the reach of your work.
C. Merino
Excellent information. Just what I was looking for.
L. H. Borrelli
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
O. O. Padron
It's an extremely useful tool.
M. M. Alv
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
I liked it — very easy to navigate. It’s the best one I’ve found.
T. Brasil
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
It gives me information on tenders that interest me. It's easy to find tenders.
A. Armenta
I’ve used another platform before, and after discovering this one, I can see it’s much better. I find my tender opportunities faster, which speeds up my work.
A. de F. Araujo
It helps me identify areas of opportunity and find tenders related to my work area.
I. J. R. Beltran
Great recommendations appear. Having the bid process link right in the email body helps a lot and saves time.
BidHits Australia helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00/month. All plans include the same features, and longer terms reduce the pro-rata cost. You can start with the free trial with no auto-charge.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits Australia shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits Australia now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1058 active users, conducted through 08/06/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
