Forms Tenders

The bid notice states The closing time for the lodgement of tenders is shown in part b.

The bid notice states he ct scanner must have a warranty of at least one year and servicing and maintenance must also be provided for nine years post warranty.

The bid notice states he tenderer who: a lodged the tender that achieves the highest score against the evaluation criteria in part b of attachment 5 and b is assessed by the customer as being fully capable of undertaking the delivery of the deliverables in accordance with the contract.

The bid notice states if the tenderer is a corporation, the tenderer must not be an externally administered body corporate as defined in section 9 of the corporations act.

The bid notice states a potential supplier must not inspect a site or sites relevant to the delivery of the deliverables except in accordance with a site inspection site inspection arranged by the potential supplier with the contact officer.

The tender states, he contract period the abs is seeking to contract for a period of three 3 years commencing in april 2026.

The evaluation criteria include extent to which the potential suppliers response meets the requirements set out in the atm, potential suppliers relevant experience and performance history demonstrated capability and capacity to provide the requirement as set out in the atm, whole of life costs to be incurred tendered price and any additional costs incurred as a result of accepting the potential suppliers offer, potential suppliers degree of compliance with the atm and draft contract, and overall risk to the abs in accepting the offer.

There are no conditions for participation.

The deadline for this request is as per the closing datetime published on vendorpanel, which is March 25, 2026. he deadline for this request is as per the closingdatetime published on vendorpanel.

The contract may be awarded to a sole or multiple respondents who best demonstrates the ability to provide quality products and/or services at a competitive price. he contract may be awarded to a sole or multiple respondents who best demonstrates the ability to provide quality products andor services at a competitive price.

Respondents must provide clear, specific and sufficiently detailed responses to each requirement. espondents must provide clear, specific and sufficiently detailed responses to each requirement.

There is no brieng or inspection for this tender. here is no brieng or inspection for this tender.

Respondents may submit a written request for clarication on any part of the request documentsprior to lodgement of their response. espondents may submit a written request for clarication on any part of the request documentsprior to lodgement of their response.

The current implementation budget is 60, 000 ex. gst and the current annual licensing budget for year one 1 is 50, 000 per annum ex. gst. he current implementation budget is 60, 000 ex. gst and the current annual licensing budget for year one 1 is 50, 000 per annum ex. gst.

The contract shall commence on the commencement date and continue in force until the date for practical completion, unless terminated earlier in accordance with this contract.

The council will pay the amount of each invoice within 30 days of its receipt except where council notifies the contractor of a dispute in accordance with clause 34 of this agreement.

The contractor warrants that where within 12 months of the completion of the works, any defect arises other than from reasonable fair wear and tear in relation to the works performed by the contractor, the contractor shall promptly upon receipt of written notice thereof from the council, at its own cost rectify the defect or reexecute or make good anything not properly performed.

The buyer is seeking submissions from suitably qualified contractors for the provision of kerb and channel construction and various concrete works.

If the works are not completed by the date for practical completion, the superintendent shall certify as due and payable to the council, liquidated damages in the amount referenced in item 17 of the schedule 1, for every day after the end date of the contract, until the works are completed to councils satisfaction.

The supplier query cutoff is Thursday 05 March 2026 12:00 am E. South America Standard Time.