Street Light Tenders

The bid notice states that an anticipated construction period of 6 months has been programmed.

The evaluation criteria and weightings are: capability and experience 20, methodology 25, social and economic factors 20, price 35.

The bid notice states that an information session will be held on site at 10am on 22 january 2026 to allow respondents to familiarise themselves with the site and project requirements.

The bid notice states that clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.

The proposed time frame for this contract is: close rfq 27th february 2026. Quotations will close: date friday 27th february 2026 time 2. 00pm aedtquotations must be lodged before the closing time.

The defect liability attached to the works is 12 months from the issue of practical completion. he defect liability attached to the works is 12 months from the issue of practical completion.

This contract will be awarded to the organization whose quotation is assessed as offering the best value. his contract will be awarded to the organisation whose quotation is assessed as offering the best value.

A pretender meeting will be held on thursday 12th february 2026 at 1pm, at the oasis aquatic centre, 50morgan st, wagga wagga. a followup pretender meeting will be held on thursday 19th february 2026 at 1pm, at the same location. a pretender meeting will be held on thursday 12th february 2026 at 1pm, at the oasis aquatic centre, 50morgan st, wagga wagga. a followup pretender meeting will be held on thursday 19th february 2026 at 1pm, at the same location.

The facility to ask questions expires five days prior to the close of quotations. he facility to ask questions expires five days prior to the close of quotations.

The deadline for this request is 10:00am, wednesday 4 march 2026 awst. The deadline for this request is 10: 00am, wednesday 4 march 2026 awst.

Contractors shall state in their quotation the period of warranty and guarantee conditions that apply against defects for the goods offered, together with any aftersales services provided. Contractors shall state in their quotation the period of warranty and guarantee conditions that apply againstdefects for the goods offered, together with any aftersales services provided.

The principal has adopted a best value for money approach to this request. he principal has adopted a best value for money approach to this request.

The city of albany is inviting proposals from qualified engineering consultancy firms to provide design and advisory services for the mcalpine residential subdivision development. he city of albany is inviting proposals from qualified engineering consultancy firms to provide design andadvisory services for the mcalpine residential subdivision development.

The city can facilitate a site visit from consultants if requested. he city can facilitate a site visit from consultants if requested.

The cut off for queries is **** on 25 february 2026 awst in order give all tenderers sufficient time to address additional information. he cut off for queries is ****on 25 february 2026 awst in order give all tenderers sufficient time to address additional information.