2026/287 Koorlong Avenue and Fourteenth Street Swale Reconstruction - Mildura Rural City Council is seeking Tender responses from suitably qualified individuals and organisations to provide civil construction and electrical works, including the removal and disposal of an existing culvert; supply and installation of a 225mm culvert; upgrade of the existing electrical switchboard and pump; construction of 4. 5m and 6m wide swales; and post- project site clean- up with reinstatement of disturbed areas and rep
Civil construction and electrical works, including the removal and disposal of an existing culvert supply and installation of a 225mm culvert upgrade of the existing electrical switchboard and pump construction of 4. 5m and 6m wide swales and postproject site cleanup with reinstatement of disturbed areas and repair of any damaged irrigation systems.
AI helper
The tender is for civil construction and electrical works. Submissions must be fully received by the closing time as late submissions will not be accepted. Council is not bound to accept the lowest priced tender or all or any part of a tender and reserves the right to conduct the request for tender process and select the successful respondents as it sees fit. All responses must be made by online submission.
The bid notice states a date for practical 30 june 2026 completion.
The bid notice states defects liability period 12 months.
The bid notice states a site inspection with council is available on request via the forum. inspections are recommended however not mandatory.
The bid notice states supplier query cutoff friday 27 february 2026 12: 00 am e. south america standard time.
CWMS Renewal- Following a recent condition assessment of Council s Community Wastewater Management System ( CWMS) , several sections of the system within the township areas have been identified as requiring immediate remediation to reinstate the network s fit, form, and function. Council is seeking suitably qualified and experienced contractors to undertake targeted repair and rehabilitation works on the identified CWMS assets. The works will include the repair, replacement, or relining of the nominated CWM
CWMS Renewal
AI helper
A briefing session will be held on 10:00 am 23 February 2026 via a Teams link. The tender closes at 5:00 pm 10 March 2026.
The bid notice states the tender closes at 5:00 pm 10 March 2026.
A briefing session will be held on 10:00 am 23 February 2026.
Provision of Kerb and Channel and Various Concrete Works - Central Goldfields Shire Council is seeking submissions from suitably qualified contractors for the provision of kerb and channel construction and various concrete works under Request for Tender G25- 26- 22. This works program forms part of the Council s ongoing infrastructure maintenance and upgrade initiatives to ensure safe and accessible public infrastructure.
Provision of kerb and channel and various concrete works
AI helper
The Central Goldfields Shire Council is seeking submissions for kerb and channel construction and various concrete works. The contract includes general conditions, special conditions, and schedules. The commencement date, practical completion date, and contract sum will be inserted after the selection of the successful tenderer. The council will pay the amount of each invoice within 30 days of its receipt. The contractor must lodge with the council the securities specified in item 16 of the schedule 1 to secure performance of the contract. Liquidated damages of $500 per day will be applied if the works are not completed by the date for practical completion.
The contract shall commence on the commencement date and continue in force until the date for practical completion, unless terminated earlier in accordance with this contract.
The council will pay the amount of each invoice within 30 days of its receipt except where council notifies the contractor of a dispute in accordance with clause 34 of this agreement.
The contractor warrants that where within 12 months of the completion of the works, any defect arises other than from reasonable fair wear and tear in relation to the works performed by the contractor, the contractor shall promptly upon receipt of written notice thereof from the council, at its own cost rectify the defect or reexecute or make good anything not properly performed.
The buyer is seeking submissions from suitably qualified contractors for the provision of kerb and channel construction and various concrete works.
If the works are not completed by the date for practical completion, the superintendent shall certify as due and payable to the council, liquidated damages in the amount referenced in item 17 of the schedule 1, for every day after the end date of the contract, until the works are completed to councils satisfaction.
The supplier query cutoff is Thursday 05 March 2026 12:00 am E. South America Standard Time.
EOI - Len T Fraser Skate Park Expansion Construction - The project involves the expansion of the existing skatepark at Len T Fraser Reserve through the construction of a new street- style skating area. Works will include specialist concrete skatepark construction and associated interface works to integrate the new elements with the existing facility and reserve. - Len T Fraser reserve is a key recreational asset within Ballarat and services a broad community user base including skateboarders, BMX riders, an
len t fraser skatepark upgrade new skate elements including a bowl and street section, with connection to the existing skatepark. the layout includes a mix of lower level plaza elements including manual pads, rails, ledges, and stair sets etc. . . there are also banked and transitioned features of varying height and complexity, from 0. 45m high 3 shallow banks, to 2. 1m high bowled quarter pipes. the obstacles have been arranged to provide lines throughout the park, with linear obstacles that can 1 be used backandforth, and banked transitioned mai features that create alternate routes and flow ad throughout the space. 3 ball court 2 open court area with 3x3 basketball court and linemarking for other informal sport activities. sheltered seating and amenities are provided adjacent to the court. subject to funding. 4 access paths social spaces 3 formalised access paths throughout the site connect the active spaces together. shaded seating areas and amenities have been 3 included in key locations to provide spectat
AI helper
The project involves the expansion of the existing skatepark at len t fraser reserve through the construction of a new streetstyle skating area. Works will include specialist concrete skatepark construction and associated interface works to integrate the new elements with the existing facility and reserve. The project will deliver new skate elements suitable for a range of age and skill levels, improve flow across the site and integrate with the existing park. In addition to the new construction, the works include minor refurbishment of the selected areas with the existing skatepark to ensure safe, consistent transition and an overall cohesive facility for the community. The closing date for the tender is March 12, 2026.
The supplier query cutoff is Monday 09 March 2026 12:00 am e. south america standard time.
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Start your free trial and receive email alerts
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/territories, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits Australia (1003 real users, 03/03/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
We selected the most helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Efficiency in search times.
R. Chavez
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
Easy to find the bids.
R. M. David
Excellent platform to help promote and expand the reach of your work.
C. Merino
With the chosen keywords, I can find many tenders of interest! I learn about new notices well in advance, giving me enough time to get organized to participate.
D. Comaq
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
It helps me identify areas of opportunity and find tenders related to my work area.
I. J. R. Beltran
It is complete and optimal, it improves my time.
R. de L. Cruz
The search tool really works and satisfactorily meets our needs.
D. L. Cairuga
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
BidHits Australia is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the Commonwealth, state/territory and local council levels. Tenders are added to the system as soon as they are published on the source portal.
Plans start at A$ 65.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia. Start by adding a few keywords. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits Australia now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1003 active users, conducted through 03/03/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
