Waste Tenders

The completion date is works to be completed within four weeks of being scheduled by council and within the contract term.

Payment terms are within 30 days of the last day of the month in which the invoice is received.

The contractor warrants that the supply will comply with all applicable requirements of the contract and industry practice.

This RFT is for the supply of suitably qualified staff and equipment to undertake vegetation management and grounds maintenance.

Liquidated damages do not apply but councils right to claim general law damages is preserved.

Supplier query cutoff is friday 06 march 2026 01: 00 am e. south america standard time.

The tenders will be assessed according to the following: mandatory criteria yesno part 3 tender response schedules all schedules yes appendix a statement of operations form yes appendix b schedule of rates yes tenders not meeting mandatory criteria may be considered nonconforming qualitative evaluation criteria weighting corporate financial capacity 15 capability experience 35 local benefit 20 price 30 total 100

It is a requirement of the queensland building and construction commission act **** qld act that a contractor must be licensed to carry our building work as that term is defined in the act the tenderers submission of a tender in response to the conditions of tender means that the tenderer irrevocably warrants that: it has considered and where required sought legal advice on the extent to which the work described in the technical specification constitutes or may constitute building work as that term is defined in the act b it holds all relevant licences required under the act or otherwise to perform the works described in the technical specification c all licences held by it under the act or otherwise are current, and are not subject to any conditions which preclude the tenderer from performing works described in the technical specification d all licences held by it under the act or otherwise which are required for the performance of the works described in the technical specification will remain current for the time during which those works are to be performed under the contract in the event that the tenderer is successful: and e it otherwise complies in all respects with the act and will continue to do so for the duration of the contract in the event that the tenderer is successful.

The question time closes on March 6, 2026, at 2:00 PM. 3 question time closes 2: 00pm 06 march 2026

The bid notice states that the contract commences on 11 July 2026 and expires 10 July 2028, with two 2 further extension options, each of up to 12 months, at councils sole discretion.

The evaluation criteria and weightings are: capability and experience 20, methodology 25, social and economic factors 20, price 35.

Clarifications cutoff for requests for clarification or further information will not be accepted on or after the date that is 3 business days prior to the closing date.

The submission deadline is stated on the cover page of this request, which is Friday, March 27, 2026, at 2:00 PM AWST. The deadline is stated on the cover page of this request

The contract may be awarded to the respondents who best demonstrates the ability to provide quality products and services at a competitive price that can achieve the towns desired outcomes. The contract may be awarded to the respondents who best demonstrates the ability to provide quality products and services at a competitive price that can achieve the towns desired outcomes.

The Town of Victoria Park invites submissions from suitably experienced respondents to provide general waste, recycling and fogo bin collection and associated services. The town of victoria park town invites submissions from suitably experienced respondentsto provide general waste, recycling and fogo bin collection and associated services asspecified in part 2.