Guardrail Package - INTRODUCTION Mackay Regional Council ( the Principal) requires the supply and installation of safety barriers at three Separable Portions within the Mackay Regional Council area, as detailed below: ( a) Site one ( 1) - 29 Glenella Richmond Road, Glenella - Separable Portion 1 ( b) Site two ( 2) - Langdon Lumburra Road, Dows Creek - Separable Portion 2 ( c) Site three ( 3) - Chain Street, Mackay - Separable Portion 3 While the Contractor may elect to commence Works concurrently across all
Guardrail Package - INTRODUCTION Mackay Regional Council ( the Principal) requires the supply and installation of safety barriers at three Separable Portions within the Mackay Regional Mackay Regional Council area, as detailed below: ( a) Site one ( 1) - 29 Glenella Richmond Road, Glenella - Separable Portion 1 ( b) Site two ( 2) - Langdon Lumburra Road, Dows Creek - Separable Portion 2 ( c) Site three ( 3) - Chain Street, Mackay - Separable Portion 3 While the Contractor may elect to commence Works concurr
supply and installation of safety barriers a site one 1 29 glenella richmond road, glenella separable portion 1 b site two 2 langdon lumburra road, dows creek separable portion 2 c site three 3 chain street, mackay separable portion 3
AI helper
The contract is proposed to commence on 07 april 2026. The separable portions must be completed as follows: a separable portion 1 29 glenella richmond road, glenella date of practical completion: 04 may 2026 b separable portion 2 langdon lumburra road, dows creek date of practical completion: 08 june 2026 c separable portion 3 chain street, mackay date of practical completion: 06 july 2026. The tender must be submitted at vendorpanel by no later than 10:00 am on 21 february 2026. Communications regarding the procurement process must be submitted to vendorpanel no tenderers: later than four 4 calendar days prior to the time stated in item 4. Respondents must provide details of similar projects completed in the last five 5 years including, a project description 20 b dollar value c client name d clients contact details and e any variations for those projects key personnel respondents must provide: 10 a details of key personnel including qualifications. Demonstrate understanding respondents must demonstrate a comprehensive understanding of the scope of works for the guardrail package including a all associated activities including supply, installation, removal, and integration with existing structures b provide proposed methodology for delivering works across multiple sites, with particular emphasis on managing operations adjacent to live traffic at two locations where no alternative 30 routes are available. This should include detailed traffic management strategies, staging plans, and worker protection measures. Outline safety requirements for works over culverts exceeding 2 metres in height. Responses should also identify key risks and mitigation strategies to ensure compliance with all relevant standards and the safe, efficient delivery of the works and a detailed construction program identifying all stages of work and c current forecast and work commitments. Tenders should not no maximum limit be longer than: 7. Tenders to be valid 90 calendar days after the time stated in item 4 as extended if at all, pursuant to the for: procurement process conditions.
The separable portions must be completed as follows: a separable portion 1 29 glenella richmond road, glenella date of practical completion: 04 may 2026 b separable portion 2 langdon lumburra road, dows creek date of practical completion: 08 june 2026 c separable portion 3 chain street, mackay date of practical completion: 06 july 2026
Respondents must return part 6aschedule of rates ms excel 40 file format. part 12request for tender page 1 relevant experience respondents must provide details of similar projects completed in the last five 5 years including, a project description 20 b dollar value c client name d clients contact details and e any variations for those projects key personnel respondents must provide: 10 a details of key personnel including qualifications. demonstrate understanding respondents must demonstrate a comprehensive understanding of the scope of works for the guardrail package including a all associated activities including supply, installation, removal, and integration with existing structures b provide proposed methodology for delivering works across multiple sites, with particular emphasis on managing operations adjacent to live traffic at two locations where no alternative 30 routes are available. this should include detailed traffic management strategies, staging plans, and worker protection measures. outline safety requirements for works over culverts exceeding 2 metres in height. responses should also identify key risks and mitigation strategies to ensure compliance with all relevant standards and the safe, efficient delivery of the works and a detailed construction program identifying all stages of work and c current forecast and work commitments. total 100
Respondents must provide details of similar projects completed in the last five 5 years including, a project description 20 b dollar value c client name d clients contact details and e any variations for those projects key personnel respondents must provide: 10 a details of key personnel including qualifications.
The briefing or site details are not applicable.
Communications regarding the procurement process must be submitted to vendorpanel no tenderers: later than four 4 calendar days prior to the time stated in item 4
Raw Water Pipeline Upgrade Ritchie' s To Mansfield Number 3 Construction - All Goulburn Valley Water Contractors who tender for work with a total of 100k or more will be required to have a third party certified safety system e. g. AS/NZS ****: **** Brief Scope: The Mansfield Raw Water System Upgrade aims to bolster and secure the raw water supply to the township of Mansfield. The project involves: i) Construction of approximately 9. 6 km long DN560mm HDPE PE100 PN16 pipeline along Delatite Lane, Mansfield-
Raw water pipeline upgrade i Construction of approximately 9. 6 km long dn560mm hdpe pe100 pn16 pipeline along delatite lane, mansfieldwoods point road, ogilvies road and highton lane. ii the design and construction of a water transfer pump station at ritchies reservoir no. 2 located on delatite lane. including the design and construction of a 5kl surge vessel. iii ancillary work: a. cap the existing raw water supply at an agreed location prior to its crossing ogilvies road, b. demolish and remove an abandoned tank and pump station approximately located at chainage **** drawing ****
AI helper
The tender is for the upgrade of a raw water pipeline. Contractors with tenders of $100k or more must have a third-party certified safety system. A compulsory site inspection is required on January 21, 2026. Questions must be submitted via the forum by January 23, 2026. The closing date for the tender is February 10, 2026. Comments on the forum cannot be posted after January 30, 2026.
The bid notice does not specify the delivery deadline.
All Goulburn Valley Water contractors who tender for work with a total of 100k or more will be required to have a third party certified safety system e. g. asnzs ****: ****.
A compulsory site inspection with representatives of the corporation is required. Location: ritchie 2 reservoir, delatite lane mansfield victoria date time: wednesday 21th january 2026 10: 00am please register your attendance by emailing : oscarr @gvwater. vic. gov. au by tuesday 20 january 2026 1pm.
Comments cannot be posted after 30 january 2026 12: 00 pm.
RFQ2026/30 4 x 2 LightTruck - Cootamundra- Gundagai Regional Council is seeking quotations for a 4 x 2 Light Truck as described in the attached specification.
4 x 2 light truck minimum 4, 500kg gvm, 4 x 2 cab chassis truck, steel tipping body with 2way tailgate, drop down sides, rope rails, minimum 650mm gap between cab and tipping body for storage box, 110 kw diesel engine automatic transmission, sideboards when unladen must be less than **** from top of sideboard to, the ground flat floor, tailgate to swing towards kerb side with spring load shotbolt tipping body headboard height approx. 600mm high, underbody telescopic hoist to be fitted with capacity to lift the fully laden tipping body. all equipment for operation to be included, fitted safety stand, clearence and taillights fitted with l. e. d lights, full specs of body to be included with quote, tow kit pintle hook, 50mm tow ball coupling, provisions for safety chains, engineer compliance plate fitted to tow bar assembly, heavy duty round trailer plug fitted, electric trailer brake controller, spare tyre mounted and fitted to truck chassis, cab to include full instrumentation, air conditioning, heart demis
AI helper
The council is seeking quotations for a 4 x 2 light truck. The price submitted will include delivery to Cootamundragundagai Regional Councils depot William Street, Gundagai. Include the provision of the vehicles first scheduled service. All vehicles are to arrive with NSW registration for a period of 12 months and include registration paperwork to demonstrate appropriate registration. Reimbursement of the cost of registration will be made separately therefore the cost of registration should be invoiced independently. Council will supply the compulsory third party insurance and the registration letter of authority to the successful supplier. Details of all warranties are to be submitted with response. All terms and conditions must be clearly stated and include detail of any nongenuine equipment fitted along with any extended warranty that may be available. The anticipated delivery timeframe is to be clearly shown in the response. The response should clearly set out what if any Australian manufactured components are to be included in the tipper truck and dog trailer offered. Quotations must detail manufacturers name and model number of each item offered quotations must provide detailed manufacture specifications and complete descriptive literature on each item offered responses must be submitted in one pdf document only.
The anticipated delivery timeframe is to be clearly shown in the response.
Details of all warranties are to be submitted with response. All terms and conditions must be clearly stated and include detail of any nongenuine equipment fitted along with any extended warranty that may be available.
Council will seek to obtain best value for money in any purchasing activity. Council will consider a minimum of the following when evaluating quotations: price operational costs product quality ongoing product support supply and delivery timeframe of quoted items as well as spare parts work health and safety benefits and risks
The respondent must complete all relevant sections. Failure to sign statement below by authorised representative will render bid invalid.
The supplier query cutoff is Thursday 22 January 2026 12:00 am E. South America Standard Time.
Port Hedland Airport Boundary fence relocation - The Bureau is seeking to find a suitably skillled and experienced supplier for the relocation of an existing boundary fe- Remove existing boundary fence ( **** meters) and supply and install approximately **** meters of new 2. 3- metre security fencing along one side of the boundary surrounding the Bureau of Meteorology Field Station, Port Hedland Airport, Western Australia. The fence will be a 2. 3- metre- high chain link fence, constructed to ****-
to establish contract for port hedland airport boundary fence relocation remove existing boundary fence **** meters and supply and install approximately **** meters of new 2. 3metre security fencing along one side of the boundary surrounding the bureau of meteorology field station, port hedland airport, western australia. the fence will be a 2. 3metrehigh chain link fence, constructed to **** with a bottom and top rail, 3. 15mm heavy duty wire plus 3strands of barbed wire as per the attached specifications refer attachment b. posts are to be spaced at 3. 2 meters unless agreed by the bureau. concrete footings to be 750mm deep for corner and gate posts, 600mm deep for the intermediate posts. ensure that all the necessary warranties on materials are provided and covered as part of the completed work. ensure that all the necessary required permits are obtained to undertake the work in a safe manner. remove old fence and rubbish from the site and ensure surrounding ground is returned to its natural stat
AI helper
The tender is for the relocation of a boundary fence at Port Hedland Airport. The closing date is Friday, August 22, 2025, at 3:00 PM VIC local time. Questions will be permitted until 5:00 PM Friday, August 15, 2025, VIC local time. Delivery is required by December 24, 2025. The contract will start on Monday, September 8, 2025, and end on Tuesday, December 30, 2025. The customer requires compliance with Australian Standards **** and **** management requirements and site hazards are detailed in appendices. The supplier must comply with the Commonwealth Supplier Code of Conduct and relevant workplace safety regulations. Payment terms are detailed in the document. Responses must be lodged electronically via Austender.
Add words related to your products or services. Our AI broadens the search so you don't miss opportunities.
2
Start your free trial and receive email alerts
Start the 14-day free trial and receive alerts with links to the documents and to the official page.
3
Adjust if needed
Add or edit keywords, set states/territories, choose your delivery schedule and email style. A map view is available in the dashboard.
What our users say
90% recommend BidHits Australia (1003 real users, 03/03/2026).Methodology
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
J. Comunale
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
Very good and accurate information about the tenders: consistent and precise.
We selected the most helpful reviews from real users. Order may change periodically.
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
Efficiency in search times.
R. Chavez
The search engine that finds what I'm looking for just by entering keywords
J. P. L. Construccion
Easy to find the bids.
R. M. David
Excellent platform to help promote and expand the reach of your work.
C. Merino
With the chosen keywords, I can find many tenders of interest! I learn about new notices well in advance, giving me enough time to get organized to participate.
D. Comaq
I get exactly what I asked for—quickly, daily, and simply. The search arrives pre-filtered, so there’s no time wasted digging through countless websites, and it’s always up to date!
P. C. O. Da Silva
It helps me identify areas of opportunity and find tenders related to my work area.
I. J. R. Beltran
It is complete and optimal, it improves my time.
R. de L. Cruz
The search tool really works and satisfactorily meets our needs.
D. L. Cairuga
Well-focused searches and highly professional service. It’s been very useful, and hiring you was the right decision. With agility and confidence in our market segment, it’s driving our revenue growth.
BidHits Australia is a public tenders search engine. We map official portals daily and deliver results on the site and by email. Our AI understands your business so you don't miss opportunities.
Just enter your email and activate the trial. For 14 days you can use all features. When it ends, if you don't subscribe at /subscription.php, the tenders list becomes limited and there are no automatic charges.
1) Choose keywords (your products or services). 2) Activate the trial and start receiving. After signup you can adjust regions, times, and email style on the settings page.
Whenever possible, yes. Some official portals require login or block direct links; in those cases we point you to the official process page so you can download the documents.
Yes. In the tenders panel you can filter by region, procurement method, dates, and value ranges. In settings you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map in the panel and see tenders by location.
AI can make mistakes. It's trained to understand your business based on the keywords you add. Refine by adding specific terms, modifying or deleting those that produce off-topic results. That trains your feed and improves future alerts.
Yes. You can query tenders via API. Documentation at /api_integration.php. Ideal for CRM, BI and automations.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there's no auto-charge.
We monitor major official portals every day at the Commonwealth, state/territory and local council levels. Tenders are added to the system as soon as they are published on the source portal.
Plans start at A$ 65.00/month. Start with the free trial--no auto-charge.
Explore a term, enable AI email alerts, access the tender documents or official portal, and filter by region and procurement method.
Transcript
Welcome to BidHits Australia. Start by adding a few keywords. Just type what you sell.
That's it. You're now ready to explore government contract opportunities made for you. Your bidding dashboard shows the latest tenders organized by date and matched to your keywords.
To help you spot the most relevant ones, your keywords are automatically highlighted in yellow.
And here's the best part. Our AI is always working behind the scenes to bring you even more opportunities.
Smart Search is already on, enhancing your results beyond exact matches. You don't have to do a thing.
Each tender card comes with useful tools. You can view a summary, open documents, favorite tenders, write private notes, remove what doesn't fit, or check the location on the map.
You can also see all tenders from the same day in a single map view. Perfect for planning your next steps. Use the search bar, apply filters, and explore with ease.
Try BidHits Australia now. It's fast, smart, and free to get started.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1003 active users, conducted through 03/03/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
