This is a public tender for home modification upgrades at 107 Francis Close, Hammond Island, QLD 4875. The contract will be awarded to the respondent who best demonstrates the ability to provide best value for money, considering both quoted price and non-price criteria. Only response schedules will be reviewed. Key referenced documents include QBuild General Terms and Conditions, QBuild Specification, and Residential Product Standards. The contractor is responsible for obtaining all necessary permits and paying all costs associated with working in Torres Strait Island communities. Work must be carried out by experienced and licensed personnel. The contractor must adhere to strict environmental and work health and safety regulations. Payment will be lump sum on completion, with progress claims considered upon request. A defect liability period of 12 months applies. The contractor must provide public and product liability insurance of $20,000,000. The tender closes on May 15, 2026.
The bid notice does not explicitly state a specific delivery deadline for the completed works. However, it mentions a ime for completion in the respondent's declaration section, implying a defined period after the work order is issued.
The bid notice states that payment will be a lump sum on completion, and progress claims will be considered upon request. The contractor will be paid within 30 days of receiving a valid tax invoice including a breakdown of rates, materials, travel, accommodation, and any other requested information.
The contractor warrants that the works will be free from any charge, liability or defect, comply with all applicable standards, and be fit for purpose and conform to the description ordered. A defect liability period of 12 months from the completion date is specified.
The engagement of services shall be awarded to the respondent who best demonstrates the ability to provide best value for money, with the quoted price and relevant non-price criteria assessed together.
The bid notice requires contractors to provide an overview of their experience and past performance in projects of similar nature, scope, and size, as well as details of the experience of personnel involved in the delivery of the works, including managerial and technical expertise.
The bid notice mentions that if the contractor fails to provide any agreed deliverable or complete any agreed milestone, they must use all reasonable endeavors to correct the issue at no additional cost to TSIRC. TSIRC may also terminate the agreement if the contractor breaches it and does not remedy the breach within seven days of notification.
The bid notice indicates attendance at site inspection na, suggesting that a site inspection is not applicable or not a mandatory part of this tender process.
The bid notice does not mention any requirement for sample submission.
The bid notice specifies a supplier query cutoff date of Friday, May 15, 2026, at 04:00 am E. South America Standard Time, which is the same as the closing date. This is likely the deadline for submitting queries or challenges.
