Enhancing Tenders

Submissions will be evaluated against criteria including commercial proposal, technical solution, operation and maintenance, and modern slavery mitigation.

Respondents must provide information to demonstrate their capability and capacity, including company profile, relevant project experience, and financial capability.

Respondents may request a site inspection by contacting procurement@muswellbrook. nsw. gov. au.

Tenderers must demonstrate compliance with applicable performance WHS legislation and council requirements.

The facility must be vacated by 18 December 2026, as this is a key project milestone. the facility must be vacated by 18 december2026.

Payments will be made in accordance with the building industry fairness security of payment act 2017. payments will be made in accordance with the building industry fairness security of payment act 2017.

The contractor shall provide warranties and certification for all services, equipment and materials at practical completion. warranties and certification for all services, equipment and materials.

The evaluation criteria include price (30%), program (25%), and methodology (25%). price 5 30 program 6 25 methodology 7 25

The successful contractor must provide evidence of contractor licences, permits, trade certification required for the undertaking of the works. evidence of contractor licences, permits, trade certification required for the undertaking of the works under the contract.

A mandatory site visit is required on Tuesday, 18 August 2026 at 9:00 am. mandatory site visit date time: tuesday, 18 august 2026 at 9: 00 am

Responses not attending the mandatory site visit will not be considered. A tender received from a tenderer that hasnot attended the mandatory site visit will not be considered.

The EOI closing date is August 27, 2026, at 2:00 pm. eoi closing date: 27th august 2026 e01 closing time: 2. 00 pm

The commercial term suggests a lease or other suitable commercial arrangement, where the successful respondent funds all costs. Council seeks commercially sustainable proposals for the delivery, operation and maintenance of publicly accessible ev charging infrastructure under a lease or other suitable commercial arrangement.

Submissions are evaluated on conformation criteria (WHS systems), performance criteria (delivery timeframe), relevant experience, commercial proposal, technical solution, and operation/maintenance. submissions will be evaluated against the following criteria: conformation criteria criteria measure reason quality of whs systems and pass fail tenderer must demonstrate compliance with applicable performance whs legislation and council requirements.

Respondents must provide a company profile, relevant project experience, financial capability, technical proposal, commercial proposal, and evidence of current insurances. as a minimum, submissions shall include a company profile, relevant project experience, financial capability, a technical proposal, a commercial proposal, an indicative project program, details of key personnel, references from similar projects, evidence of current insurances, and information outlining the respondents work health and safety whs management systems.

Respondents may request a site inspection by contacting ***@***. *. * may request a site inspection by contacting procurement@muswellbrook. nsw. gov. au.

Failure to demonstrate compliance with applicable performance WHS legislation and council requirements is a pass/fail criterion. tenderer must demonstrate compliance with applicable performance whs legislation and council requirements.