Site Commissioning Tenders

Completion of all components of the works, including commissioning, is required by 17 December 2027. completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site, including labour, plant, and installation, or for materials delivered to site. progress claims may be submitted for works fully executed on site

The contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection. the contractor is responsible to provide 12 months warranty on all workmanship

Contractors must have necessary skills and expertise, and complete the Contractor WHS Questionnaire. the respondent is responsible for and warrants that it has: . . . the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. failure to maintain progress in accordance with the approved project schedule . . . may result in the application of liquidated damages

There is no mandatory site visit, but requests are welcome via the Vendor Panel question portal. there is no mandatory site visit for these works, but requests for a site visit during the tender period are welcome.

Any form of canvassing or direct contact with council employees, councillors, or consultants is strictly prohibited and will result in automatic disqualification. any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification

Payment is made via progress claims. GAWB issues a progress certificate within 10 business days after receiving a payment claim, and pays within 5 business days after the certificate date. gawb must pay that amount to the contractor subject to gawbs rights of setoff under the agreement within 5 business days after the date of the progress certificate.

Contractor must be a suitable qualified and experienced contractor and must provide information relating to key personnel, qualifications, licenses, experience and other evidence requested.

Completion of all works, including commissioning, is required by 17 December 2027. The contract states: completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. The contract states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

The contractor provides a 12-month warranty on all workmanship from practical completion. The contract states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Submissions are assessed on multiple criteria including price, past performance, technical expertise, WHS systems, availability, and local contractor status. The document states: tendered prices, past performance of respondent, suitability of technical expertise methodology in the delivery of the service, contractor whs systems, availability, and local contractor.

The works must be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor. The document states: the works shall be undertaken by a suitably qualified, experienced and appropriately licensed electrical contractor with the skills and resources necessary to complete the works safely.

Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.

There is no mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact with council employees, councillors, or consultants is prohibited and will result in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

Completion of all works including commissioning is required by 17 December 2027. The document states: completion of all components of the works, including commissioning, is required by 17 december 2027.

Progress claims may be submitted for works fully executed on site or materials delivered to site. The document states: progress claims may be submitted for works fully executed on site, including any associated labour, plant, and installation, or for materials procured and delivered to site ready for use.

The contractor provides 12 months warranty on all workmanship from practical completion. The document states: the contractor is responsible to provide 12 months warranty on all workmanship from the date of the practical completion inspection.

Contractors must have necessary skills and expertise. The document states: the contractor warrants that it has the necessary skills and expertise to be able to competently supply the scope of works.

Failure to maintain progress may result in liquidated damages. The document states: failure to maintain progress in accordance with the approved project schedule. . . may constitute a breach of the contract and may result in the application of liquidated damages.

No mandatory site visit, but requests are welcome. The document states: there is no mandatory site visit for these works but requests for a site visit during the tender period are welcome.

Direct contact with council employees or councillors results in automatic disqualification. The document states: any breach of this protocol, including direct contact outside the approved channel, will result in automatic disqualification from the contracting process.

The pressure sewer system, tank and connection to riser main at boundary is a PC item of $300,000.