Motor Vehicle Cargo Terminal SP1 - The purpose of the project is to undertake the drainage, service- interface and security works required to improve the existing drainage corridor and secure the existing Benwell Road car park. These works also support the Port' s future development of additional motor vehicle and cargo storage capacity, which does not form part of this Contract. The recent construction of the Dedicated Laydown Area and the East Port Connection Road changed the available capacity and draina
Drainage, service interface, and security works Drainage corridor improvement, security works for Benwell Road car park, modification of drainage channel, erosion protection, service relocation/protection/installation, security fencing/gates/signage/bat deflectors, pavement marking/signage modification, landscaping/revegetation/erosion and sediment controls, temporary works.
AI helper
The project involves drainage, service interface, and security works to improve the existing drainage corridor and secure the Benwell Road car park. The tender requires submission of a conforming tender, which must comply with all conditions. A mandatory tender briefing/site inspection is scheduled for 15/09/2026. Offers must be lodged electronically by 29/09/2026 at 5:00pm EST. Evaluation criteria include mandatory criteria (insurance, modern slavery, Qld government code of conduct, previous performance) and qualitative criteria (local benefits, region/community benefits, capability, quality).
The criteria include mandatory criteria like insurance compliance, modern slavery compliance, qld governments code of conduct compliance, previous performance and/or referee reports verified and qualitative criteria like local benefits, including local workforces and use of local suppliers in the supply chain.
Tenderers must meet mandatory criteria including insurance compliance, modern slavery compliance, qld governments code of conduct compliance, previous performance and/or referee reports verified.
A tender briefing site inspection is scheduled for 1: 00pm, tuesday ****.
A tenderer who directly or indirectly canvasses support from an employee, contractor or agent of the port will be disqualified.
**** - Stormwater Upgrades - Sunshine Coast Stadium North, Bokarina - Stage 1A - This project includes removal of the existing trunk line and installation of the new reinforced concrete box culverts and stormwater infrastructure, it will involve some disruption to businesses on Trade Lane and will require the contractor to manage Traffic and pedestrians in a live environment. There will be some access constraints due to Stadium events, and this will need to be built into the Contractors program. Works wi
Stormwater upgrades Removal of existing trunk line, installation of new reinforced concrete box culverts and stormwater infrastructure, dewatering, acid sulphate soil management, groundwater control, access chamber construction, lake kawana outlet works, reconstruction of revetment walls, trade lane reinstatement, sportsman parade reinstatement, sewer realignment and replacement, temporary relocation of the pontoon, site demobilisation and project completion documentation.
AI helper
This lump sum contract involves the removal of an existing trunk line and installation of new reinforced concrete box culverts and stormwater infrastructure at Sunshine Coast Stadium North, Bokarina Stage 1A. The contractor must manage traffic and pedestrians in a live environment, accounting for stadium event access constraints. Council will supply all RCBC culverts; the contractor supplies other materials, plant, and labour. The tender closes on 22 September 2026. Evaluation criteria include capability and experience (20%), methodology (40%), social and economic factors (20%), and price (20%).
The evaluation criteria and weightings are: capability and experience 20, methodology 40, social and economic factors 20, price 20.
Any prohibited contact with a local government employee or elected member of council may result in the respondent or prospective respondent and their tender being disqualified from the tender process.
**** - Lambert Street Reconstruction from Drummond Street to Leschenault - SLK 0. 0- 0. 28 - Please refer to the Tender documentation and attachments - Please ensure you have addressed the selection criteria and attached with your submission
Street reconstruction Replacement of existing and installation of new stormwater drainage pits, pipes covers and grates; replacement of existing road pavement; sealing and asphalting; installation of kerbing, pram ramps, driveway aprons and crossovers; removal and installation of concrete paths; installation of road markings and signage; associated traffic management and preliminaries.
AI helper
The City of Albany seeks a civil construction contractor for the Lambert Street reconstruction project. Works must be planned to maximize activities during the school holidays (December 19, 2026, to February 1, 2027). The contractor must supply all plant, materials, and labor, manage traffic, and provide a site supervisor. The evaluation uses a best value for money approach. A mandatory site inspection is scheduled for September 1, 2026. The submission deadline is September 17, 2026, at 10:00 am AWST.
The deadline for this request is 10:00am awst, thursday 17september 2026.
Prices tendered are to be on a schedule of rates basis.
The contract shall be in force for the period until the end of the defects liability period twelve 12 months from award of practical completion.
The principal has adopted a best value for money approach to this request.
Offers that do not contain all information requested as per selection criteria will be excluded from evaluation.
Tenderers are required to attend a site inspection on tuesday 1 september 2026 at 8: 30am.
An offer may be rejected without consideration of its merits in the event that: a it is not submitted before the deadline or it is not submitted at the place specified in the request or c it fails to comply with any other requirements of the request.
ITT264 - Streetscape Upgrade - Mill and Currie Streets Nambour - Sunshine Coast Council is seeking a suitably qualified contractor to construct streetscaping, roadworks and a signalised crossing at, and adjacent to the intersection of Mill and Currie Streets, Nambour. The scope of work includes, but is not limited to: o Signalised pedestrian crossing o Lighting o Road pavement works o Concrete pavement construction; o Paved pathway construction; o Landscaped gardens; o Concrete driveways and kerb ramps; o S
Streetscaping, roadworks and signalised crossing construction Signalised pedestrian crossing, lighting, road pavement works, concrete pavement construction, paved pathway construction, landscaped gardens, concrete driveways and kerb ramps, signage and line marking, kerb channel works, stormwater drainage works, supply and installation of precast islands, public utility alterations.
AI helper
Sunshine Coast Council seeks a qualified contractor for streetscaping, roadworks, and a signalised crossing at Mill and Currie Streets, Nambour. The contract is lump sum, requiring the contractor to provide all materials, plant, and labour. Contractors must hold a minimum TMR prequalification of R2 B1 F5. Tenders close at 12noon on October 6, 2026. Evaluation includes mandatory criteria (Health and Safety, Compliance) and weighted criteria (Capability and Experience 20%, Methodology 25%, Social and Economic Factors 20%, Price 35%).
Tenders will be evaluated against prescribed evaluation criteria, with price weighted at 35% and capability/experience at 20%.
Contractors are required to hold a minimum TMR prequalification of R2 B1 F5.
The entire site is accessible to the public, and respondents are encouraged to attend the works site to gain a full understanding of the project.
Direct contact with any elected member of council or local government employee regarding any part of this tender, other than those listed in schedule 1 item 5, is prohibited.
Rosny Tennis Courts - Retaining Wall Repair and Fencing - Council invites Tenders to undertake works as specified in these Tender Documents for the following works at the Rosny Tennis Club, 18 Bastick Street, Rosny Rosny Tennis Club, Retaining Wall repairs - Supply of all materials and consumables for retaining wall repairs - Supply of portable toilet and amenities for the duration of all works - Retaining wall repairs as per design drawings - Reinstating the Bessa brick wall and returfing - Removal and app
Retaining wall repair and fencing Retaining wall repairs, supply of materials for retaining wall repairs, supply of portable toilet and amenities, reinstating bessa brick wall and returfing, removal and disposal of waste materials, fencing upgrades, supply of materials for fencing and footings, removal of existing courts, installation of footings, installation of court drainage, installation of new black chain link fencing.
AI helper
Council invites tenders for retaining wall repairs, fencing upgrades, and associated works at Rosny Tennis Club. Works must be completed prior to 30 Nov 2026. A pretender site meeting is scheduled for 17 September 2026. Tender closes on 06 October 2026. All works must comply with Safe Work Australia code of practice.
All site works must be completed prior to 30 Nov 2026.
A pretender site meeting is scheduled for 11am on thursday 17 september onsite.
Set your alerts once. Let opportunities come to you.
1
Tell us what you sell
Add keywords for your products or services. Smart matching helps find tenders that do not use the exact same words.
2
Start the free trial and receive alerts
Start the 14-day free trial and receive alerts with links to documents or official pages.
3
Fine-tune your feed
Adjust keywords, states/territories, delivery times and email style. Use filters and map view when needed.
What our users say
All tenders related to our product are captured by you and sent to us. In my opinion, it’s perfect—broad coverage and easy searches across the tender documents.
R. M. Ferreira
They deliver on their promises. The information is simple and straightforward.
G. G
They provide information on a wide and varied range of purchasing processes. All the necessary details are also included.
J. M. Defelitto
I receive the tenders in a timely and proper manner.
R. Rama
I closed deals thanks to the information gathered by the search tool. There’s no need to research across multiple media outlets.
We selected helpful reviews from real users. Order may change periodically.
Very good and accurate information about the tenders: consistent and precise.
G. R. Ortiz
The idea of ​​using a keyword and sending the information by email is very good.
U. Solutions
The tool is truly effective at scanning tender documents, efficiently delivering bids.
G. D. Reis
You see a lot of tenders; you get emails with the alerts.
M. Camarasa
I liked the way they search for tenders and provide us with the link to view them.
C. J. P. Perez
The information helps me submit my bids on time for tenders, and I also have readily available information on upcoming tenders. So far, I am very satisfied with what I have received.
M. A. Z. Armenta
Excellent information. Just what I was looking for.
L. H. Borrelli
I consistently received notifications about tenders within the specific segment I chose to monitor. The system simplifies processes that used to be complex, offering a navigation experience that is easy, fast, and modern.
G. P. da S. E. Guimaraes
It encompasses all portals in one place.
G. Ferrea
A very good platform.
D. C. Espinosa
Simple, easy to use, and always up to date.
J. Z. Abi-zaid
It’s one of the best platforms for searching bids.
BidHits helps businesses find Australian public tenders. We monitor official portals daily, organise opportunities in one place, and deliver results on the site and by email.
Enter your email and activate the trial. For 14 days you can use all features. If you do not subscribe at /subscription.php when it ends, the tender list becomes limited and there are no automatic charges.
No. We monitor major official portals and bring matching opportunities into one workflow. You can receive alerts by email on the schedule you choose.
Whenever possible, yes. Some official portals require login or block direct links. In those cases, we point you to the official process page so you can access the documents there.
Yes. In the tenders panel you can filter by state/territory, procurement method, dates and value ranges. In settings, you can save preferences for future alerts and searches.
Yes. After signup you can switch to the map view and see tenders by location.
Smart matching helps find opportunities related to what you sell, even when a tender uses different wording. It can make mistakes, so you can improve results by adding, editing or removing keywords.
Yes. You can query tenders via API and receive data in JSON or XML. Documentation is available at /api_integration.php.
In Settings you can pause alerts or adjust delivery times. If you want to delete your account, just contact us. During the free trial there is no auto-charge.
We monitor major official portals every day at Commonwealth, state/territory and local council levels. Tenders are added as soon as they are available from the source portal.
Plans start at A$ 65.00 per month, with options for different business needs and billing terms. Start with a free trial and evaluate the results before subscribing, with no automatic billing.
Search a term, receive smart email alerts, open documents or official pages, and filter by region and procurement method.
Transcript
Welcome to BidHits.
Finding public tenders and bids is important. But what really matters is quickly identifying the opportunities that match what your company sells.
To get started, enter a few keywords that describe your products or services. BidHits shows relevant opportunities, highlights your keywords, and organizes everything by date.
Smart search is already enabled and uses artificial intelligence to expand your results, even when the tender uses different words from the ones you searched for.
For each opportunity, you can view a summary, access documents, mark it as a favorite, add private notes, remove what is not relevant, or view it on the map.
You can also use filters, run searches, and explore the day's opportunities directly on the map.
Start using BidHits now. It's fast, practical, and you can try it for free.
AI Assistant
Ask me about the tender...
Loading summary...
Methodology
Unaided survey with 1097 active users, conducted through 18/09/2026.
Single question: "Would you recommend our services to a friend or colleague?" - 90% answered "yes".
